Ordinance No. 11,365ORDINANCE NO, 11 ,365
AN 0RDINANCI? (A' TI HE CATY (20UNC I L 01"'I'l I I ', CA Y 0FI1AY-F0\VN, "1'1,,,X AS,
A(JTII0RIZING AND DHU,(7FING 'ITIL' CTIN MANAGER TO EXF'(:UFF' AND
THE CITY C'LERK 11) ATTEST 11) 'I�'IIF PROFESSIONAL SI`,AVICTS
AGRF,EMI`,NT WITII BIJR.Y i PARTNIA6, INC"., FOR ENGINF.A.,RING Sl�,RVIC.'1 S
FOR TIll-', 2007 STRFF.TBOND PROGRAM - YEAR 3; AUT110JUZING IIAYNI NT
HYTHF, (ATY 0FI3AY'I"0\,VN IN AN AM( UNTNOTTO EXCEE'D SIX I 1UNDRI-A)
FORTY-1-ACAIT THOUSAND T11REF, IIIJNDRI,'A) AND NO/100 DOLLARS
(S648300MI); MAKIN(; OTIJER PROVISdONS RLA-ATED TIIEIkF'F0, AND
PROVIDING FOR I'1 -11a 1 I '*F,4.,k`FIVE
* * * * * * * * * * * *, * * * * * * 1, * * * * * * * * * * * * * * * * * * * * * * * * * * * 4, * * * * * 4, * * * * * * * * * * * * * * * * * * * * * 4: * * * * * ** * *10:
SeetJon 1: That the City Council of, the C11y of' Baytown, Texas, hereby authorizes and
directs the City Manager to execute and the City (lot to MMM to tile Professional Services Agreement
with Bury -- Patiners, Inc., Ior equineering services Or the 2007 Street Bond Prograin - Year 3. A copy,
cal "' the agreement is mtackd %-CtO, 11larked Exhibit "A," and made a part hereol'tor aH intents and
Purposes.
Sect on 2: "least the City C7ouncil of the (Vity of lbywn audwrizes payment lo l3wT +
lAwMcM hw, in tiara aniount not to exceed SIX HUNDRED FORTY-EK31 IT 'I'llOUSAND TJH(EE,
11UNDRI-A) AND NO/100 DOLLARS ($648,300AO) Or engheerhg services & accordmwe wAh die
agreurnern awhorized in Scction I hercinabove.
ScHmi 3: That the Oty Nil►mgu is hereby gruted genend authody to approve to deacase
or an incmasc ire coos hyl'VVENTY41VE "II R)IJSP%NI)AP41)IN(,,)/100 DOLLARS($25,00( MO) car less,
pmvWcd that Me amoum amborized in Section 2 here0i'may not he increased by more than twenly-five
1wivent (25%). 11,71
INTRODUC'U',I), KFAD, and PASSED by We allknlative v( tile City Comwil of Me chy of
Bogown. this the 20 day of N4,201 T �f A4
III H,N 11, DOWARLOS, Mayor
A 119 P
dlAci iR z A c
AI1'PR0VI-,'D AS TO F()KNI:
e,71 iNAC,'10 RAMIREZ S it), Attorney
41� �C� I �,
L A w I QW K mn H.` n C M 6 wmdu JWW n A W Mq A7 � lmti - Vm 4rm A DO) SCwofflomjj
URTr A
STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
THIS AGREEMENT clTective as of the _ day of May, 2010 (-Effective Date").
[Jetween
City of Baytown ( "OWNER ")
and
Bury + Partners, Inc. ( "ENGINEER ")
OWNER intends to contract for engineering services in connection with the 2007 Street Bond Program — Year 3,
including the reconstruction, paving, drainage and utility improvements for the following streets located in Baytown,
I larris County. Texas:
I
Gresham Ave.
Rice
Harvard
Residential
Asphalt
I
Louisiana St.
New Jersey
Michigan
Residential
Asphalt
2
W. James Ave.
N. Commerce
N. Main
Collector
Asphalt
2
Rosewood Dr.
Memorial
Oakmont
Residential
Concrete
2
Felton St.
Lindenvood
Brentwood
Residential
Concrete
2
N. Jones St.
W. Sterling
W. Lobit
Residential
Asphalt
3
Timber lane
Jasmine
Meador
Minor Arterial
Asphalt
A
Inwood Dr.
N. Pruett
606 Inwood
Collector
Concrete
( "Project ")
OWNER and ENGINEER in consideration of their mutual covenants as set forth herein agree as follows:
Standard Norm of Agreement
Between Owner and Engineer for Professional Services
Page 1 of 12
TABLE OF CONTENTS fe
ARTICLE 1- SERVICES OF ENGINEER ......................................................................................... ............................... 3
1.01 Scope ................................................................................................................................. ............................... 3
ARTICLE 2 - OWNER'S RESPONSIBILITIES ...................»........................................................... ............................... 3
2.01 General ............................................................................................................................... ............................... 3
ARTICLE 3 - TIMES FOR RENDERING SERVICES ..........................»........................................... ............................... 3
3.01 General ............................ ......................... »................ .......... ....................... »................................................. 3
3.02 Suspension ..................................... ...»......................»..........................».....».................. ............................... 3
ARTICLE 4 - PAYMENTS TO ENGINEER ..... . ........... » .....................»........................................... ............................... 3
4.01 Methods of Payment for Services and Reimbursable Expenses of ENGINEER ............. ............................... 3
4.02 Other Provisions Concerning Payments ............» .............................................................. ............................... 3
ARTICLE 5 - OPINIONS OF COST . .................................... »........».............»........................»....... ............. »................. 4
5.01 Opinions of Probable Construction Cost ............................».................................»......... ............................... 4
5.02 Designing to Construction Cost Limit .............................................................................. ............................... 4
5.03 Opinions of Total Project Costs ........................................................................................ ............................... 4
ARTICLE 6 - GENERAL CONSIDERATIONS ..............................................................................». ............................... 4
6.01 Standards of Performance ...............»................................................................................. ............................... 4
6.02 Authorized Project Representatives ............................»..................................................... ............................... 5
6.03 Design without Construction Phase Services ................................................................... ........_...................... 5
6.04 Use of Documents .............................................................................................................. ............................... S
6.05 Insurance ............................................................................................................................. ............................... 6
6.06 Termination ....................................................................................................................... ............................... 6
6.07 Controlling Law ..............................»................................................................................. ............................... 7
6.08 Successors. Assigns, and Beneficiaries ........................................................................... ».............................. 7
6.09 Dispute Resolution ............................................................................................................. ............................... 7
6.10 Hazardous Environmental Condition ............................................................................... ............................... 7
6.11 Allocation of Risks ............................................................................................................. ............................... 8
6.12 Notices ................................................................................................................................ ............................... 8
6.13 Survival.._ .................................».....»........»...........................................».....»....»...»....... ............................... 8
6.14 Severability .................................................... » ............. ... .......... ......... _ ..... » ..... .. ................ .. .......... .............. 8
6.15 Waiver ..................................................................................................................»............ ............................... 8
6.16 Headings ............................................................................................................................. ............................... 8
ARTICLE7 - DEFINITIONS .............................................................................................................. ............................... 8
7.01 Defined Terms ..................................................................»...................».......................... ............................... 8
ARTICLE 8 - EXHIBITS AND SPECIAL PROVISIONS ................................................................ ...............................
8.01 Exhibits Included ....................... ............................. . ...................................................................................... 11
8.02 Total Agreement ............................................................................................................... ...............................
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 2 or 12
ARTICLE 1 - SERVICES OF ENGINEER
1.01 Scope
A. ENGINEER shall provide the Basic and Additional
Services set forth herein and in Exhibit A.
B. (modified) Upon issuance of a notice to proceed by
the OWNER. ENGINEER is authorized to begin Basic
Services as set forth in Exhibit A.
C. (Deleted).
ARTICLE 2 - OWNER'S RESPONSIBILITIES
2.01 General
A. OWNER shall have the responsibilities set forth
herein and in Exhibit B.
ARTICLE 3 -TIMES FOR RENDERING SERVICES
3.01 General
A. (Modified) ENGINEER's services and
compensation under this Agreement have been agreed to for
the design of the Project together with other services specified
in Exhibit A. ENGINEER's obligation to render services
hereunder will be for whatever period necessary for the final
completion of said services.
B. (Deleted).
C. (Modified) For purposes of this Agreement the term
"day" means a calendar day of 24 hours.
102 Suspension
A. (Deleted)
B. (Modified) If ENGINEER's services are delayed or
suspended in whole or in part by OWNER. ENGINEER may
be entitled to equitable adjustment of rates and amounts of
compensation provided for elsewhere in this Agreement to
reflect. reasonable costs incurred by ENGINEER in
connection with, among other things, such delay or
suspension and reactivation and the fact that the time for
performance under this Agreement has been revised, unless
such delay or suspension is caused in whole or in part by the
ENGINEER, its officers, agents, or employees. If Engineer
causes or contributes to the delay or suspension. ENGINEER
shall have no right to seek additional compensation.
ARTICLE 4 - PAYMENTS TO ENGINEER
4,01 Methods of Payment for Services and
Reimbursable Expenses of ENGINEER
A. For Basic Services. OWNER shall pay ENGINEER
for Basic Services performed or furnished under Exhibit A.
Part I. as set forth in Exhibit C.
B. For .IMdonal Services. OWNER shall pay
ENGINEER for Additional Services performed or furnished
under Exhibit A. Part 2, as set forth in Exhibit C.
C. (Modified) For Reimbursable Expenses. In
addition to payments provided for in paragraphs COLA and
4.01.8. OWNER shall pay ENGINEER for Reimbursable
Expenses incurred by ENGINEER and ENGINEER's
Consultants as set forth in Exhibit C. However. all expenses
associated with meals and lodging must be approved in
writing by OWNER prior to ENGINEER incurring any
expense associated therewith: otherwise. the parties hereto
agree and understand that OWNER shall not be liable and
ENGINEER shall not make a claim against OWNER for any
such expenses.
4.02 Other Provisions Concerning Payments
A. Preparation of Invoices. Invoices will be prepared
in accordance with OWNERS standard processing practices
and will be submitted to OWNER monthly via mail or email
by ENGINEER, unless otherwise agreed. ENGINEER shall
supply detailed back -up information along with each invoice
in order for the OWNER to effectively evaluate the fees and
charges. The amount billed in each invoice will be calculated
as set forth in Exhibit C.
B. (Modified) Payment of Invoices. Invoices are due
and payable within 30 days after the receipt of the invoice and
the necessary backup information. If OWNER fails to make
any payment due ENGINEER for services and expenses
within 30 days after receipt of ENGINEEWs invoice and the
required backup documentation therefor, the amounts due
ENGINEER will accrue interest at the rate set forth in
Section 2251.025 of the Texas Government Code (or the
maximum rate of interest permitted by law. if less) after the
30th day. ENGINEER may after giving seven days' written
notice to OWNER suspend services under this Agreement
until ENGINEER has been paid in full all amounts due for
services, expenses, and other related charges. However. it is
expressly understood and agreed that ENGINEER will not
Standard Form of Agreement
Between Owner and Engineer for professional Services
Page 3 of 12
charge any interest or penalty as set forth herein on any
portion of an invoice that is disputed and/or withheld in
accordance with paragraph 4.02 and that ENGINEER will not
suspend services under the agreement on account of a
disputed invoice or on account of monies withheld. All
payments will be credited first to principal and then to
interest.
C. Disputed Invoices. In the event of a disputed or
contested invoice, only that portion so contested may be
withheld from payment, and the undisputed portion will be
paid.
D. Payments Upon Termination. In the event of any
termination under section 6.06, ENGINEER will be entitled
to invoice OWNER and will be paid in accordance with
Exhibit C for all services performed or furnished and all
Reimbursable Expenses incurred through the effective date of
termination provided all instruments of service have been
tendered to the OWNER..
2. (Deleted)
E. (Modified) Recordr of ENGINEER's Costs.
Records of ENGINEEWs costs pertinent to ENGINEER's
compensation under this Agreement shall be kept in
accordance with generally accepted accounting practices.
Copies of such records will be made available to OWNER
upon request at no cost to OWNER.
F. Legislative Actions. In the event of legislative
actions after the Effective Date of the Agreement by any level
of government that impose taxes, fees, or costs on
ENGINEER's services or other costs in connection with this
Project or compensation therefor, such new taxes, fees, or
costs shall be invoiced to and paid by OWNER as a
Reimbursable Expense to which a Factor of 1.0 shall be
applied. Should such taxes, fees, or costs be imposed, they
shall be in addition to ENGINEER's estimated total
compensation.
G. (Added) Indebtedness. If ENGINEER, at any time
during the term of this agreement, incurs a debt, as the word
is defined in section 2.662 of the Code of Ordinances of the
City of Baytown, it shall immediately notify the OWNER's
Director of Finance in writing. If the OWNER's Director of
Finance becomes aware that the ENGINEER has incurred a
debt, the OWNER's Director of Finance shall immediately
notify the ENGINEER in writing. If the ENGINEER does
not pay the debt within 30 days of either such notification,
the OWNER's Director of Finance may deduct funds in an
amount equal to the debt from any payments owed to the
ENGINEER under this Agreement. and the ENGINEER
waives any recourse therefor.
ARTICLE 5 - OPINIONS OF COST
5.01 Opinions of Probable Construction Cost
A. ENGINEER's opinions of probable Construction
Cost provided for herein are to be made on the basis of
ENGINEER's experience and qualifications and represent
ENGINEER's best judgment as an experienced and qualified
professional generally familiar with the industry. However,
since ENGINEER has no control over the cost of labor,
materials, equipment, or services furnished by others, or over
the Contractor's methods of determining prices, or over
competitive bidding or market conditions, ENGINEER
cannot and does not guarantee that proposals, bids, or actual
Construction Cost will not vary from opinions of probable
Construction Cost prepared by ENGINEER. If OWNER
wishes greater assurance as to probable Construction Cost,
OWNER shall employ an independent cost estimator as
provided in Exhibit B.
5.02 Designing to Construction Cost Limit
A. (Deleted).
5.03 Opinions of Total Project Costs
A. (Deleted)
ARTICLE 6 - GENERAL CONSIDERATIONS
6.01 Standards of Performance
A. (Modified) The standard of care for all professional
engineering and related services performed or furnished by
ENGINEER under this Agreement will be the care and skill
ordinarily used by members of ENGINEER's profession
practicing under similar circumstances at the same time and in
the same locality.
B. (Modified) ENGINEER shall be responsible for the
technical accuracy of its services and documents resulting
therefrom, and OWNER shall not be responsible for
discovering deficiencies therein. ENGINEER shall correct
such deficiencies without additional compensation except to
the extent such action is directly attributable to deficiencies in
OWNER - furnished information upon which ENGINEER is
authorized to rely as provided in Section 6.01.E.
C. ENGINEER shall perform or fumish professional
engineering and related services in all phases of the Project to
which this Agreement applies. ENGINEER shall serve as
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 4 of 12
OWNER's prime professional for the Project. ENGINEER
may employ such ENGINEER's Consultants as ENGINEER
deems necessary to assist in the performance or furnishing of
the services. ENGINEER shall not be require) to employ any
ENGINEER's Consultant unacceptable to ENGINEER.
D. ENGINEER and OWNER shall comply with
applicable Laws or Regulations and OWNER - mandated
standards. This Agreement is based on these requirements as
of its Effective Date. Changes to these requirements after the
Effective Date of this Agreement may be the basis for
modifications to OWNER's responsibilities or to
ENGINEER's scope of services, times of performance. or
compensation.
E. (Modified) OWNER shall be responsible for, and
ENGINEER may rely upon, the accuracy and completeness
of all requirements, programs, instructions, reports, data, and
other information famished by OWNER to ENGINEER
pursuant to this Agreement, unless expressly stated or
communicated otherwise by OWNER. ENGINEER may use
such requirements, reports, data, and information in
performing or furnishing services under this Agreement.
F. OWNER shall make decisions and carry out its other
responsibilities in a timely manner and shall bear all costs
incident thereto so as not to delay the services of
ENGINEER.
G. Prior to the commencement of the Construction
Phase, OWNER shall notify ENGINEER of any variations
from the language indicated in Exhibit E. "Notice of
Acceptability of Work," or of any other notice or certification
that ENGINEER will be requested to provide to OWNER or
third parties in connection with the Project. OWNER and
ENGINEER shall reach agreement on the terns of any such
requested notice or certification, and OWNER shall authorize
such Additional Services as are necessary to enable
ENGINEER to provide the notices or certifications requested.
H. (Modified) ENGINEER shall not be required to sign
any documents, no matter by whom requested, that would
result in ENGINEER's having to certify. guarantee or
warrant the existence of conditions whose existence
ENGINEER cannot ascertain; provided. that ENGINEER has
exercised due diligence and was not otherwise required to
certify, guarantee or warrant the existence of such conditions.
I. During the Construction Phase, ENGINEER shall
not supervise, direct, or have control over Contractor's work,
nor shall ENGINEER have authority over or responsibility
for the means. methods, techniques, sequences. or procedures
of construction selected by Contractor. for safety precautions
and programs incident to the Contractor's work in progress,
nor for any failure of Contractor to comply with Laws and
Regulations applicable to Contractor's furnishing and
Worming the Work.
J. (Modified) ENGINEER neither guarantees the
performance of any Contractor nor assumes responsibility for
any Contractor's failure to furnish and perform the Work in
accordance with the Contract Documents. However. nothing
contained in this paragraph shall be construed so as to absolve
ENGINEER from liability for any such failure about which
ENGINEER knew or should have known existed in the
exercise of ENGINEER's services under this Agreement.
K. (Modified) ENGINEER shall not be responsible for
the acts or omissions of any Contractor's), subcontractor or
supplier, or of any of the Contractor's agents or employees or
any other persons (except ENGINEER's own employees and
its consultants for which it is legally liable) at the Site or
otherwise furnishing or performing any of the Contractor's
work; or for any decision made on interpretations or
clarifications of the Contract Documents given by OWNER
without consultation and advice of ENGINEER.
L. (Modified) The General Conditions for any
construction contract documents prepared hereunder are to be
the Standard Form of Agreement between Owner and
Contractor and as approved by OWNER in writing.
6.02 Authorized Project Representatives
A. Contemporaneous with the execution of this
Agreement, ENGINEER and OWNER shall designate
specific individuals to act as ENGINEER's and OWNER's
representatives with respect to the services to be performed or
famished by ENGINEER and responsibilities of OWNER
under this Agreement. Such individuals shall have authority
to transmit instructions. receive information, and render
decisions relative to the Project on behalf of each respective
ply.
6.03 Design without Construction Phase Services
(Deleted)
6.04 Use of Documents
A. (Modified) Upon execution of this Agreement, the
ENGINEER grants to the OWNER an ownership interest in
the Instruments of Service. The ENGINEER shall obtain
similar interests from the OWNER and the ENGINEER's
consultants consistent with this Agreement. Within seven
days of any termination or expiration of this Agreement. the
ENGINEER shall be required to tender to OWNER all
Instruments of Service; provided OWNER has paid all
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 5 of 12
monies, excluding any disputed amount, due and owing to
ENGINEER in accordance with this Agreement. With such
ownership interest, it is expressly understood by the parties
hereto that the OWNER may use the Instruments of Service
for any purposes which the OWNER sees fit, including, but
not limited to, subsequent construction, reconstruction,
alteration, and/or repairs of the Project. As a condition to the
OWNER's use of the Instruments of Service, the OWNER
hereby expressly agrees to remove the ENGINEER's name
and all references to the ENGINEER. and its consultants from
the Documents. The OWNER hereby releases any and all
claims which the OWNER could make arising out of or in
connection with any reuse of the documents by the OWNER
This release of claims for the matters covered in this
Paragraph 6.04.A shall be for the benefit of the ENGINEER,
its officers. and employees and sub - consultants, as well as
their successors and assigns.
B. (Modified) Copies of OWNER- fumished data that
may be relied upon by ENGINEER are limited to the printed
copies that are delivered to ENGINEER pursuant to Exhibit B
unless otherwise expressly stated or communicated by
OWNER. Files in electronic media format of text, data,
graphics. or of other types that are furnished by OWNER to
ENGINEER are only for convenience of ENGINEER. Any
conclusion or information obtained or derived from such
electronic files will be at the user's sole risk.
C. Copies of Documents that may be relied upon by
OWNER are limited to the printed copies (also known as hard
copies) that are signed or sealed by the ENGINEER. Files in
electronic media format of text, data, graphics, or of other
types that are furnished by ENGINEER to OWNER are only
for convenience of OWNER. Any conclusion or information
obtained or derived from such electronic files will be at the
user's sole risk.
D. Because data stored in electronic media format can
deteriorate or be modified inadvertently or otherwise without
authorization of the data's creator, the party receiving
electronic files agrees that it will perform acceptance tests or
procedures within 60 days, after which the receiving party
shall be deemed to have accepted the data thus transferred.
The parry delivering the electronic riles will correct any errors
detected within the 60-day acceptance period. ENGINEER
shall not be responsible to maintain documents stored in
electronic media format after acceptance by OWNER.
E. When transferring documents in electronic media
format, ENGINEER makes no representations as to longterm
compatibility, usability, or readability of documents resulting
from the use of software application packagm operating
systems, or computer hardware differing from those used by
ENGINEER at the beginning of this Project.
F. ( Modified) Any use of the Documents on any
extension of the Project or on any other project shall be at
OWNER's sole risk and OWNER hereby releases
ENGINEER from any liability associated solely with the
reuse of the Documents.
G. If there is a discrepancy between the electronic files
and the hard copim the hard copies govern.
H. Any verification or adaptation of the Documents For
extensions of the Project or for any other project will entitle
ENGINEER to further compensation at rates to be agreed
upon by OWNER and ENGINEER.
6.05 Insurance
A. ENGINEER shall procure and maintain insurance as
set forth in Exhibit G. "Insurance:'
B. Not used.
C. Not used.
D. Not used.
E. Not used.
F. At any time. OWNER may request that
ENGINEER. at OWNER's sole expense, provide additional
insurance coverage, increased limits, or revised deductibles
that are more protective than those specified in Exhibit G. if
so requested by OWNER, with the concurrence of
ENGINEER. and if commercially available, ENGINEER
shall obtain and shall require ENGINEER's Consultants to
obtain such additional insurance coverage, different limits, or
revised deductibles for such periods of time as requested by
OWNER. and Exhibit G will be supplemented to incorporate
these requirements.
6.06 Termination
A. (Modified) The obligations hereunder may be
terminated:
1. For cause,
a. (Modified) By either parry upon 30 days
written notice in the event of failure by the other
party to perform in accordance with the terns hereof
through no fault of the terminating party: or
b. By ENGINEER upon seven days written
notice if ENGINEER is being requested by
OWNER to furnish or perform services contrary to
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 6 of 12
ENGINEER's responsibility as a licensed
professional.
c. Notwithstanding the foregoing, this
Agreement will not terminate as a result of such
substantial failure if the party receiving such notice
begins, within seven days of receipt of such notice,
to correct its failure to perform and proceeds
diligently to cure such failure within no more than
30 days of receipt thereof, provided, however, that if
and to the extent such substantial failure cannot be
reasonably cured within such 30 day period, and if
such parry has diligently attempted to cure the same
and thereafter continues diligently to cure the same
then the cur: period provided for herein shall extend
up to, but in no case more than 60 days after the date
of receipt of the notice.
2. For comvnience by OWNER effective upon the
receipt of notice by ENGINEER.
B. Not used.
6.07 Controlling Law
A. This Agreement is to be governed by the law of the
state in which the Project is located.
6.08 Successors, Assigns, and Benefleiaries
A. OWNER and ENGINEER each is hereby bound and
the partners, successors, executors. administrators and legal
representatives of OWNER and ENGINEER (and to the
extent permitted by paragraph 6.08.8 the assigns of OWNER
and ENGINEER) are hereby bound to the other party to this
Agreement and to the partners, successors, executors,
administrators and legal representatives (and said assigns) of
such other party, in respect of all covenants, agreements and
obligations of this Agreement.
B. Neither OWNER nor ENGINEER may assign,
sublet, or transfer any rights under or Interest (including, but
without limitation, moneys that are due or may become due)
in this Agreement without the written consent of the other,
except to the extent that any assignment, subletting, or
transfer is mandated or restricted by law. Unless specifically
stated to the contrary in any written consent to an assignment,
no assignment will release or discharge the assignor from any
duty or responsibility under this Agreement.
C. Unless expressly provided otherwise in this
Agreement:
1. Nothing in this Agreement shall be construed to
create. impose, or give rise to any duty owed by
OWNER or ENGINEER to any Contractor, Contractor's
subcontractor, supplier, other individual or entity, or to
any surety for or employee of any of them.
2. All duties and responsibilities undertaken
pursuant to this Agreement will be for the sole and
exclusive benefit of OWNER and ENGINEER and not
for the benefit of any other patty. The OWNER agrees
that the substance of the provisions of this paragraph
6.08.0 shall appear in the Contract Documents.
6.09 Not Used.
6.10 Hazardous Environmental Condition
A. OWNER represents to Engineer that to the best of its
knowledge a Hazardous Environmental Condition does not
exist.
B. (Modified) OWNER has disclosed to the best of
its knowledge and belief to ENGINEER the existence of all
Asbestos. PCB's. Petroleum, Hazardous Waste, or
Radioactive Material located at or near the Site. including
type, quantity and location.
C. (Modified) if a Hazardous Environmental
Condition is encountered or alleged. ENGINEER shall have
the obligation to notify OWNER on or before the next
business day of the same.
D. It is acknowledged by both parties that
ENGINEER's scope of services does not include any services
related to a Hazardous Environmental Condition. In the event
ENGINEER or any other party encounters a Hazardous
Environmental Condition, ENGINEER may. at its option and
without liability for consequential or any other damagm
suspend performance of services on the portion of the Project
affected thereby until OWNER: (i) retains appropriate
specialist consultant(s) or contractors) to identify and, as
appropriate, abate, remediate, or remove the Hazardous
Environmental Condition; and (ii) warrants that the Site is in
full compliance with applicable Laws and Regulations.
E. OWNER acknowledges that ENGINEER is
performing professional services for OWNER and that
ENGINEER is not and shall not be required to become an
"arranger," 'operator," "generator," or "transporter" of
hazardous substances. as defined in the Comprehensive
Environmental Response. Compensation, and Liability Act of
1990 (CERCLA), which are or may be encountered at or near
the Site In connection with ENGINEEWs activities under this
Agreement.
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 7 of 12
F. If ENGINEER's services under this Agreement
cannot be performed because of a Hazardous Environmental
Condition, the existence of the condition shall justify
ENGINEER's terminating this Agreement for cause on 30
days notice.
6.11 Allocation of Risks
A. (Modified) Indemnification. See Exhibit K.
6.12 Notices
A. (Modified) Any notice required under this
Agreement will be in writing, addressed to the appropriate
party at its address on the signature page and given
personally, or by registered or certified mail postage prepaid,
or by a commercial courier service. Additionally. notices
may be given via facsimile or by electronic mail if such notice
is also given personally, or by registered or certified mail or
by a commercial courier service. All notices shall be effective
upon the date of receipt.
6.13 Survival
A. (Modified) All express representations,
indemnifications, and limitations of liability included In this
Agreement will survive its completion or termination for any
reason.
6.14 Severability
A. Any provision or part of the Agreement held to be
void or unenforceable under any Laws or Regulations shall be
deemed stricken, and all remaining provisions shall continue
to be valid and binding upon OWNER and ENGINEER. who
agree that the Agreement shall be reformed to replace such
stricken provision or part thereof with a valid and enforceable
provision that comes as close as possible to expressing the
intention ofthe stricken provision.
6.15 Waiver
A. Non - enforcement of any provision by either party
shall not constitute a waiver of that provision, nor shall it
affect the enforceability of that provision or of the remainder
of this Agreement.
6.16 Headings
A. The headings used in this Agreement are for general
reference only and do not have special significance.
ARTICLE 7 - DEFINITIONS
7.01 Defined Terms
A. Wherever used in this Agreement (including the
Exhibits hereto) and printed with initial or all capital letters,
the terms listed below have the meanings indicated, which
are applicable to both the singular and plural thereof-
]. Jddenda —Written or graphic instruments issued
prior to the opening of Bids which clarify, correct. or change
the Bidding Documents.
2. .4dditionat Services —The services to be performed
for or fumished to OWNER by ENGINEER in accordance
with Exhibit A. Part 2 of this Agreement.
3. .agreement This "Standard Form of Agreement
between OWNER and ENGINEER for Professional
Services;' including those Exhibits listed in Article 8 hereof.
4. . f pplicalion for Payment —The form acceptable to
ENGINEER which is to be used by Contractor in requesting
progress or final payments for the completion of its Work and
which is to be accompanied by such supporting
documentation as is required by the Contract Documents.
S. rIsbesros --Any material that contains more than one
percent asbestos and is friable or is releasing asbestos fibers
into the air above current action levels established by the
United States Occupational Safety and Health Administration.
6. Barrie Services —The services to be performed for or
furnished to OWNER by ENGINEER in accordance with
Exhibit A. Part 1. of this Agreement.
7. Bid—The offer or proposal of the bidder submitted
on the prescribed form setting forth the prices for the Work to
be performed.
8. Rlddtng Documents —The advertisement or invitation
to Bid, instructions to bidders, the Bid form and attachments,
the Bid bond. if any, the proposed Contract Documents, and
all Addenda, if any.
9. Change Order —A document recommended by
ENGINEER. which is signed by Contractor and OWNER to
authorize an addition, deletion or revision in the Work. or an
adjustment in the Contract Price or the Contract Times, issued
on or after the Effective Date of the Construction Agreement.
10. Construction .4greement —The written instrument
which is evidence of the agreement, contained In the Contract
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 8 of I3
Documents, between OWNER and Contractor covering the
Work.
11. Construction Contract —The entire and integrated
written agreement between the OWNER and Contractor
concerning the Work.
12. Construction Cast --The cost to OWNER of those
portions of the entire Project designed or specified by
ENGINEER. Construction Cost does not include costs of
services of ENGINEER or other design professionals and
consultants, cost of land, rights-of-way, or compensation for
damages to properties, or OWNER's costs for legal,
accounting, insurance counseling or auditing services, or
interest and financing charges incurred in connection with the
Project, or the cost of other services to be provided by others
to OWNER pursuant to Exhibit B of this Agreement.
Construction Cost is one of the items comprising Total
Project Costs.
13. (Modified) Contract Documents — Documents that
establish the rights and obligations of the parties engaged in
construction and include the Construction Agreement
between OWNER and Contractor and all documents
referenced therein, Addenda (which pertain to the Contract
Documents), Contractor's Bid (including documentation
accompanying the Bid and any post -Bid documentation
submitted prior to the notice of award) when attached as an
exhibit to the Construction Agreement, the notice to proceed,
the bonds, appropriate certifications, insurance documents
the General Conditions, the Supplementary Conditions. the
Specifications and the Drawings as the same are more
specifically identified in the Construction Agreement,
together with all Written Amendments, Change Orders. Work
Change Directives, Field Orders, and ENGINEER's written
interpretations and clarifications issued on or after the
Effective Date of the Construction Agreement. Approved
Shop Drawings and the reports and drawings of subsurface
and physical conditions are not Contract Documents.
14. Contract Price --The moneys payable by OWNER to
Contractor for completion of the Work in accordance with the
Contract Documents and as stated in the Construction
Agreement.
15. Contract 77mes —The numbers of days or the dates
stated in the Construction Agreement to: (i) achieve Final
Completion, and (ii) complete the Work so that it is ready for
final payment as evidenced by ENGINEER's written
recommendation of final payment.
16. Contractor —An individual or entity with whom
OWNER enters into a Construction Agreement.
IT Correction Period! The time after Final Completion
during which Contractor must correct, at no cost to OWNER.
any Defective Work, normally one year after the date of Final
Completion or such longer period of time as may be
prescribed by laws or Regulations or by the terns of any
applicable special guarantee or specific provision of the
Contract Documents.
I S. Defective - -An adjective which, when modifying the
word Work, refers to Work that is unsatisfactory. faulty, or
deficient, in that it does not conform to the Contract
Documents, or does not meet the requirements of any
inspection, reference standard, test, or approval referred to in
the Contract Documents, or has been damaged prior to
ENGINEER's recommendation of final payment.
19. Documents —Data, reports. Drawings, Specifications,
Record Drawings, and other deliverables, whether in printed
or electronic media format, provided or furnished in
appropriate phases by ENGINEER to OWNER pursuant to
this Agreement.
20. Drawings --That part of the Contract Documents
prepared or approved by ENGINEER which graphically
shows the scope. extent, and character of the Work to be
perforated by Contractor. Shop Drawings are not Drawings
as so defined.
2l. Effective Date of the Construction Agreement —The
date indicated in the Construction Agreement on which it
becomes effective, but if no such date is indicated, it means
the date on which the Construction Agreement is signed and
delivered by the last of the two parties to sign and deliver.
22. Effective Date of the Agreement —The date indicated
in this Agreement on which it becomes effective, but if no
such date is indicated, it means the date on which the
Agreement is signed and delivered by the last of the two
parties to sign and deliver.
23. UGINEER's Consultants -- individuals or entities
having a contract with ENGINEER to furnish services with
respect to this Project as ENGINEER's independent
professional associates, consultants, subcontractors, or
vendors. The term ENGINEER includes ENGINEER's
Consultants.
24. Field Order --A written order issued by ENGINEER
which directs minor changes in the Work but which does not
involve a change in the Contract Price or the Contract Times.
25. Final Completion shall mean that all work has
been completed, all final punch list items have been
inspected and satisfactorily completed, all payments to
subcontractors have been made. all documentation and
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 9 of 12
warranties have been submitted. all closeout documents
have been executed and approved by the OWNER, and the
Project has been finally accepted by the OWNER.
26. General Conditions -That part of the Contract
Documents which sets forth terns, conditions, and procedures
that govern the Work to be performed or furnished by
Contractor with respect to the Project.
27. Ht ardous Environmental Condition—The presence
at the Site of Asbestos, PCB's, Petroleum. Hazardous Waste,
or Radioactive Materials in such quantities or circumstances
that may present a substantial danger to persons or property
exposed thereto in connection with the Work.
28. l/ccardous lVaste —The tern Hazardous Waste shall
have the meaning provided in Section 1004 of the Solid
Waste Disposal Act (42 USC Section 6903) as amended from
time to time.
29. l rnvs and Regulations, Lmvs or Regulations —Any
and all applicable laws, rules, regulations, ordinances, codes,
standards. and orders of any and all governmental bodies,
agencies. authorities. and courts having jurisdiction.
30. PCB's -- Polychlorinated biphenyls.
31. Petraleum— Petroleum, including crude oil or any
fraction thereof which is liquid at standard conditions of
temperature and pressure (60 degrees Fahrenheit and 14.7
pounds per square inch absolute), such as oil. petroleum. fuel
oil. oil sludge. oil refuse, gasoline, kerosene, and oil mixed
with other non - Hazardous Waste and crude oils.
32. Radioactive Uaterials— Source. special nuclear, or
byproduct material as defined by the Atomic Energy Act of
1954 (42 USC Section 2011 et seq.) as amended from time to
time.
33. Record Drawings The Drawings as issued for
construction on which the ENGINEER. upon completion of
the Work, has shown changes due to Addenda or Change
Orders and other information which ENGINEER considers
significant based on record documents famished by
Contractor to ENGINEER and which were annotated by
Contractor to show changes made during construction.
34. Reimbursable Expenses --The expenses incurred
directly by ENGINEER in connection with the performing or
furnishing of Basic and Additional Services for the Project for
which OWNER shall pay ENGINEER as indicated in Exhibit
C.
35. Resident Project Representative —The authorized
representative of ENGINEER, if any, assigned to assist
ENGINEER at the Site during the Construction Phase. The
Resident Project Representative will be ENGINEER's agent
or employee and under ENGINEER's supervision. As used
herein. the term Resident Project Representative includes any
assistants of Resident Project Representative agreed to by
OWNER. The duties and responsibilities of the Resident
Project Representative are as set forth in Exhibit D.
36. Samples Physical examples of materials,
equipment, or workmanship that are representative of some
portion of the Work and which establish the standards by
which such portion of the Work will be judged.
37. Shop Drmyings »All drawings, diagram.
illustrations, schedules, and other data or information which
are specifically prepared or assembled by or for Contractor
and submitted by Contractor to ENGINEER to illustrate some
portion of the Work.
38. Site — lands or area indicated in the Contract
Documents as being furnished by OWNER upon which the
Work Is to be performed, rights -of -way and easements for
access thereto, and such other lands furnished by OWNER
which are designated for use of Contractor.
39. Specfcations --That part of the Contract Documents
consisting of written technical descriptions of materials,
equipment, systems, standards, and workmanship as applied
to the Work and certain administrative details applicable
thereto.
40. Substantial Completion —The time at which the
Work (or a specified part thereof) has progressed to the point
where, in the opinion of ENGINEER, the Work (or a
specified part thereof) is sufficiently complete, in accordance
with the Contract Documents. so that the Work (or a specified
part thereof) can be utilized for the purposes for which it is
intended. The terms "substantially complete" and
"substantially completed" as applied to all or part of the Work
refer to Substantial Completion thereof.
41. Supplementary Condlllons That part of the Contract
Documents which amends or supplements the General
Conditions.
42. (Modified) 7bial Project Cases —The sum of the
Construction Cost, allowances for contingencies, the total
costs of services of ENGINEER or other design professionals
and consultants, oast of land, rights -of -way. compensation for
damages to properties, OWNER's costs for legal, accounting,
insurance counseling or auditing services. interest and
financing charges Incurred in connection with the Project, and
the cost of other services to be provided by others to OWNER
pursuant to Exhibit B of this Agreement.
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 10 of 12
43. Mark—The entire completed construction or the
various separately identifiable parts thereof required to be
provided under the Contract Documents with respect to this
Project. Work includes and is the result of performing or
famishing labor, services, and documentation necessary to
produce such construction and famishing, installing, and
incorporating all materials and all equipment into such
construction, all as required by the Contract Documents.
44. Work Change Directive --A written directive to
Contractor issued on or after the Effective Date of the
Construction Agreement and signed by OWNER upon
recommendation of the ENGINEER, ordering an addition,
deletion. or revision in the Work, or responding to differing
or unforeseen subsurface or physical conditions under which
the Work is to be performed or to emergencies. A Work
Change Directive will not change the Contract Price or the
Contract Times but is evidence that the parties expect that the
change directed or documented by a Work Change Directive
will be incorporated in a subsequently issued Change Order
following negotiations by the parties as to its effect, if any, on
the Contract Price or Contract Times.
45. Written Anwadment —A written amendment of the
Contract Documents signed by OWNER and Contractor on or
after the Effective Date of the Construction Agreement and
normally dealing with the non - engineering or non- technical
rather than strictly construction- related aspects of the Contract
Documents.
ARTICLE 8 - EXHIBITS AND SPECIAL
PROVISIONS
8.01 Exhibits included
A. Exhibit A, "ENGINEEWs Services:' consisting of
eight (8) pages.
B. Exhibit B, "OWNER's Responsibilities." consisting
of two (2) pages.
C. Exhibit C. "Payments to Engineer for Services and
Reimbursable Expenses," consisting of two (2) pages.
D. Exhibit D, "Duties, Responsibilities and Limitations
of Authority of Resident Project Representative, " is not used.
E. Exhibit E, "Notice of Acceptability of Work." is not
used.
F. Exhibit F, "Construction Cost Limit," is not used.
G. Exhibit G, "Insurance," consisting oftwo (2) pages.
H. Exhibit H, "Dispute Resolution," is not used.
I. Exhibit 1, "Allocation of Risks." is not used.
J. Exhibit J, "Special Provisions° is not used.
K. (Added) Exhibit K. "Indemnification" consisting of
two (2) pages.
8.02 Total Agreement
A. This Agreement (consisting of pages 1 to 12
inclusive, together with the Exhibits identified above)
constitutes the entire agreement between OWNER and
ENGINEER and supersedes all prior written or oral
understandings. This Agreement may only be amended.
supplemented. modified. or canceled by a duly executed
written instrument. This Agreement along with the exhibits
shall be head and construed as the same Agreement.
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page I I of 17
IN WITNESS WHEREOF. the parties hereto have executed this Agreement, the Effective Date of which is
indicated on page 1.
OWNER: CM' OF BAYTOWN
Signature:
Printed Name: Garrison C. Brumback
"Title: City Manager
Date Signed:
Address for giving notices:
P.O. Box 434
Baytown. Texas 77522
Designated Representative (paragraph 6.03.A):
Name: Jose A. Pastmun. P.E.
Title: Director of Engineering
Phone Number: (281).120-715-1
Facsimile Number. (381) 420 -6586
E-\lail Address: josc.pasttatt:t4?baytown.org
1:NGINEER: BU tY* R'11tERS- MOU,INC.
Signature: _
Printed Name: _Bob D. Boozer. P.E.. CDP
'title: _ Managing Principal
Date Signed: $-V/7 I D
If if
Address forgiving notices:
1001 W. Loop South, Suite 300
I louston, Texas 77027
Designated Representative (paragraph 6.03.A):
Name: Patrick J. [toss. P.F.
Tille: Senior Associate
Phone Number: (713) 313 -0011
Facsimile Number (71333) 313 -0010
F.Mail Address: prossnbutypartners.cont
Standard Form of agreement
Between O%wer and Engineer for Professional Services
Page 12 of 12
This is EXHIBIT A. consisting of 8 pages. referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Initial:
OWNER
ENGINEER
ENGINEER'S Services
Article I of the Agreement is amended and supplemented to include the following agreement of the panics.
ENGINEER shall provide Basic and Additional Services as set forth below.
PART I -- BASIC SERVICES (Modified)
A1.01 Preiiirrivaty Design Phccve
A. ENGINEER shall:
1. Consult with OWNEIt to define and clarify OWNER's requirements 11ir the Project and available data.
2. Advise OWNER as to the necessity of OWNER's providing data or services of the types described in
Exhibit 13. which are not part of ENGINE ICs Basic Services. and assist OWNER in obtaining such
data and services.
3. (Nelodilied) Identify. consult with, and analyze requirements of governmental authorities having
jurisdiction to approve the portions of the Project designed or specified by ENGINEER. including, but
not limited to, mitigating measures identified in the environmental assessment (if any).
4. Identify and evaluate potential solutions available to OWNER: and, alter consultations with OWNER,
recommend to OWNER those solutions which in ENGINEER's judgment meet OWNER's
requirements for the Project.
5. (Modified) Attend meetings with OWNER to receive input into OWNER'S requirements for the
Project and evaluation of potential solutions available to OWNER and to discuss and finalize design
criteria and acquire pertinent information regarding the Project.
6. ( Modified) Perform or provide the following additional Preliminary Dcsign Phase tasks or delivernbles:
a. Conduct a kickoff meeting with I"NGINL•ER'S gcoleclmical consultant and the OWNER.
b. Compile a list of design criteria /assumptions /exceptions for the street rehabilitation program for
the OWNER's review and approval, including. but not limited to:
I. I-landling of stnrctures /fences /landscaping/lrces encroaching in the right -of -way;
2. Replacement of existing utilities within the right -of -way and those within three -feet
3. of back -of -curb;
•1. Developing paving options that include adjustments due to change in elevation, profile
adjustments, driveways, intersections, manholes or curb ramps if applicable;
5. Reviewing side slopes and roadside ditch grades due to changes in elevation if applicable:
6. Developing a policy regarding areas with existing drainage issues where flooding presently
occurs;
7. Upgrading utilities that are not currently in compliance with City design criteria, or arc
within 3 feet of the back -of -curb;
S. Handling of mailboxes, sidewalks, landings. and retaining wall replacement;
9. Handling of through the curb drains, driveway culverts, and private irrigation systems
within the right- of-way; and
Page 1 of 8 Pages
(E XHII31'1' A - Scope of Work)
10. Developing policy regarding return curbs at driveways for curb and gutter and open ditch
roadways.
11. Developing policy regarding parking areas within the existing right -of- -way and total width
of driveway(s) allowed; and
12. Developing policy regarding wheelchair ramps.
c. Retrieve water. sanitary sewer and storm sewer block maps, designated AsBuilts/Record
Drawings. LIDAR. 0 & M records, and private utility records for each street. Coordinate with
private utility companies regarding their utility maintenance/replacement schedules and locations
as putt of the data collection cfforts.
d. Perform a visual inspection of the streets Identified as pan of the Project.
e. Verify pavement conditions and existing utility locations.
E Assess all potential right -of -way conflicts as well as compliance with design criteria developed
above.
g. Photograph the streets for record purposes.
h. Attend a City Council workshop session to present the study results.
7. (Modified) Prepare a summary report (the "Report ") which will contain findings, comparisons of
alternatives, and recommendations for the Project. This Report will be accompanied by ENGINEER's
opinion of Total Project Costs for each solution which is so recommended for the Project with each
component separately itemized, including the following, which will be separately itemized: opinion of
probable Construction Cost, allowances for contingencies and for the estimated Total Project Costs.
The Report shall include an overall exhibit showing the Project streets and the photographs of the
streets.
8. Furnish six (6) review copies of the Draft Report to OWNER within ninety (90) calendar days of
authorization to begin services and review it with OWNER.
9. Revise the Draft Report in response to OWNER's and other parties' comments, as appropriate. and
furnish fourteen (14) final copies of the revised Report to the OWNER within ten (10) calendar days
after completion of reviewing it with OWNER.
B. (Modified) ENGINEER's services under the Preliminary Design Phase will be considered complete on the
date when the final copies of the revised Report has been delivered to and accepted by OWNER.
A 1.02 Final Design Phase
A. Upon written authorization from OWNER. ENGINEER shall:
1. (Modified) Prepare final Drawings indicating the scope, extent, and character of the Work to be
performed and furnished by Contractor. Specifications will be prepared, where appropriate, in
conformance with the 16- division format of the Construction Specifications Institute or other format
agreed to in writing by OWNER and ENGINEER.
2. Provide technical criteria. written descriptions, and design data for OWNER's use in filing applications
for permits from or approvals of governmental authorities having jurisdiction to review or approve the
final design of the Project and assist OWNER in consultations with appropriate authorities.
3. Advise OWNER of any adjustments to the opinion of probable Construction Cost and any adjustments to
Total Project Costs known to ENGINEER.
4. Perform or provide the following additional final Design Phase tasks or deliverables:
a. Prepare design plans and technical specifications for the proposed paving, drainage. and
utility improvements for the reconstruction of the streets. which constitute the Project;
b. Provide layouts and details for signing, pavement markings, and ADA ramps as required.
Page 2 of 8 Pages
(EXHIBIT A - Scope of Work)
c. Prepare both the written Storm Water Pollution Prevention Plan along with drawings and
details.
d. Prepare traffic control plans for the proposed improvements in accordance with the Texas
Manual on Uniform Traffic Control Devices (TMUTCD).
e. Prepare roadway cross - sections and compute embankment excavation quantities.
E Prepare quantity take -oil's and an opinion of probable construction cost for the proposed
improvements at the 30%, 60%, 90%, and 1000/6 milestones. The deliverables for the 30 %,
and 60 0/6, milestones regarding the plans shall only include submittal of the plan and profile
sheets.
g. The Contract Documents shall be included with the plans for both the 900/6 and 100°Yo percent
submittals.
h. Prepare project specific construction notes and specifications.
i. The standard OWNER detail sheets for water. sewer, and storm and the standard OWNER
detail sheet for paving details and typical cross-sections shall be included in the project plans.
j. Prepare Project specific construction notes.
k. Cause to be performed the following services:
1. Surveying.
A detailed topographical survey for each street segment identifying the evident rights -of-
way will be performed. The survey shall establish surveying limits based on the best
available information. This shall include a limit of 300 feet within the existing right-of-
way in each direction for all intersections with the exception of Barrymore. Bury will
survey within the existing rights-of-way the intersecting streets along Barymore down to
the next intersection in each direction. The extra surveying efforts will assist to ascertain
the existing drainage patterns. Further, the surveying fee is based on the premise that
Bury will have adequate control placed on the construction plans and the selected
contractor will be responsible for construction staking.
3. Geotechnical Investigation.
Geotechnical services for the Project shall be provided in accordance with applicable
City requirements.
3. Urban Forestry
Urban forestry services for the Project shall be provided in accordance with applicable
City requirements.
4. Environmental Investigations
Environmental services shall be provided on an as needed basis if conditions found in the
field warrant environmental investigation. These services will not be performed unless
authorized in advance by the City in writing. These services, If authorized,
may include:
(a) Perform a Preliminary Environmental Site Assessment (PESA) substantially in
accordance with current ASTM Guidelines for existing and proposed ROW.
(b) Provide a cultural resources survey (records search only). A letter requesting
concurrence with findings and recommendations shall be sent to the Texas Historical
Commission.
I. All geometric design shall be in conformance with the applicable City standards, except
when variances are permitted. applicable Harris County standards. and TMUTCD.
m. Prepare and update the project schedule outlining the submittal dates and project completion
milestones for the 909/0, and 100% submittals to the OWNER.
n. Consult with the OWNER and affected utility companies to define and clarify the project
requirements and available related data
o. Meet and coordinate with the OWNER, Harts County Flood Control District (HCFCD),
stakeholders, utility owners. as needed to facilitate coordination and approval of the
Construction Documents.
p. Prepare for and attend project status meetings with the OWNER.
q. The project will require plans to be reviewed in accordance with Texas Architectural Barriers
Project Registration (TABPR) guidelines. We will submit the drawings to a state licensed
reviewer for review and approval. ENGINEER will prepare the TABPR application and
estimate the review fee. ENGINEER will submit the completed application and a set of
Page 3 of 9 Pages
(EXHIBIT A - Scope of Work)
construction drawings to the reviewer for review and approval. ENGINEER will coordinate
with the reviewer to address comments. Once all comments have been cleared, the project
will be registered with the Texas Department of Licensing and Regulations (TDLR). The
application fee along with any review fee(s) required by either the TABPR or TDLR will be a
reimbursable expense and therefore, will be billed as such.
r. Deliverables shall include construction documents submitted to the OWNER at the 309/0,
60%. 40'/0, and 1000/. milestones for review. comments, and approvals. The 100 percent
submittal will include the final contract documents including specifications.
s. The fins) Contract Documents will be supplied by the OWNER as the standard Hams County
specifications will be incorporated by reference.
5. Prepare and furnish Bidding Documents for review and approval by OWNER, its legal counsel, and other
advisors, as appropriate, and assist OWNER in the preparation ofother related documents.
6. Submit 5 final copies of the Bidding Documents and a revised opinion of probable Construction Cost to
OWNER within two hundred ten (210) days after authorization to proceed with this phase.
7. (Added) Prepare additional line items in the Bid Tabulations, assuming the project documentation,
including plans and specifications, were originally prepared to reflect these items. as reasonably requested
by OWNER. so long as this/these request(s) is made prior to the preparation of the final bid documents.
B. In the event that the Work designed or specified by ENGINEER is to be performed or furnished under more
than one prime contract, or if ENGINEER's services are to be separately sequenced with the work of one or
more prime Contractors (such as in the case of fast - tracking). OWNER and ENGINEER shall, prior to
commencement of the Final Design Phase. develop a schedule for performance of ENGINEER's services
during the Final Design. Bidding or Negotiating. Construction. and Post - Construction Phases in order to
sequence and coordinate properly such services as are applicable to the work under such separate prime
contracts. This schedule is to be prepared and included in or become an amendment to Exhibit A whether or
not the work under such contracts is to proceed concurrently.
C. The number of prime contracts for Work designed or specified by ENGINEER upon which the ENGINEER's
compensation has been established under this Agreement is one (1).
D. (Modified) ENGINEER's services under the Final Design Phase will be considered complete on the date
when the submittals required by paragraph A 1.03.A.6 have been delivered to and accepted by OWNER.
A 1.03 Bung or Negotiating Phase
A. After acceptance by OWNER of the Bidding Documents and the most recent opinion of probable
Construction Cost as determined in the Final Design Phase, and upon written authorization by OWNER to
proceed, ENGINEER shall:
1. Assist OWNER in advertising for and obtaining bids for the Work and provide 15 sets of plans and
specifications.
2. Answer questions and issue Addenda as appropriate to clarify, correct, or change the Bidding Documents.
3. Consult with OWNER as to the acceptability of subcontractors. suppliers, and other individuals and
entities proposed by Contractor for those portions of the Work as to which such acceptability is required
by the Bidding Documents.
4. Perform or provide the following additional Bidding or Negotiating Phase tasks or deliverables:
a. Recommend award to the OWNER.
b. Attend the Council meeting for award of the contract for the Project.
Page 4 of 8 Pages
(EXHIBIT A - Scope of Work)
S. (Modified) Attend the Mandatory Pm -Bid Conference and the Bid opening, prepare Bid tabulation sheets,
assemble contract documents, assist OWNER in both evaluating Bids or proposals and awarding
contracts for the Work.
6. (Added) Assist in connection with Bid protests. rebidding, or re- negodating contracts for construction,
materials, equipment, or services.
B. (Modified) The Bidding or Negotiating Phase will be considered complete upon commencement of the
Construction Phase.
A 1.04 Constnretion Phase
A. Upon successful completion of the Bidding and Negotiating Phase, and upon written authorization from
OWNER. ENGINEER shall:
I. General rldwinWrallon of Consinection Contract. Consult with OWNER and act as OWNER's
representative as provided in the General Conditions. The extent and limitations of the duties.
responsibilities and authority of ENGINEER as assigned in said General Conditions shall not be
modified, except as ENGINEER may otherwise agree in writing. All of OWNER's instructions to
Contractor will be issued through ENGINEER, who shall have authority to act on behalf of OWNER
in dealings with Contractor to the extent provided in this Agreement and said General Conditions
except as otherwise provided in writing.
2. (Modified) Selecting Independent Testing Laboratory. Assist OWNER in the selection of an
independent testing laboratory to perform the services identified in paragraph B2.01.0, if any.
3. Pre- Constniction Conference. Participate in a Pre- Construction Conference prior to commencement
of Work at the Site.
4. Baselines and Benchmarks. As appropriate, establish control and temporary benchmarks for locating
the Work which in ENGINEER's judgment are necessary to enable Contractor to proceed.
S. Visits to Site and Observation of Construction. In connection with observations of Contractor's work
in progress while it is in progress:
a. (Modified) Make visits to the Site at intervals appropriate to the various stages of construction,
appropriate to verify Contractor's payment requests, and as ENGINEER and/or OWNER deems
necessary, in order to observe as an experienced and qualified design professional the progress
and quality of the Work. Such visits and observations by ENGINEER, and the Resident Project
Representative, if any, are not intended to be exhaustive or to extend to every aspect of
Contractor's work in progress or to involve detailed inspections of Contractor's work in
progress beyond the responsibilities specifically assigned to ENGINEER in this Agreement and
the Contract Documents, but rather are to be limited to spot checking, selective sampling, and
similar methods of general observation of the Work based on ENGINEER's exercise of
professional judgment as assisted by the Resident Project Representative, if any. Based on
information obtained during such visits and such observations, ENGINEER will determine if
Contractor's work is proceeding in accordance with the Contract Documents, and ENGINEER
shall keep OWNER informed of the progress of the Work.
b. (Modified) The purpose of ENGINEER's visits to. and representation by the Resident Project
Representative, if any. at the Site. will be to enable ENGINEER to better carry out the duties and
responsibilities assigned to and undertaken by ENGINEER during the Construction Phase, and,
in addition. by the exercise of ENGINEER's efforts as an experienced and qualified design
professional, to provide for OWNER a greater degree of confidence that the completed Work
will substantially conform to the Contract Documents and that the integrity of the design concept
Page 5 of g Pages
(EXHIBIT A - Scope of Work)
of the completed Project as a functioning whole as indicated in the Contract Documents has
been implemented and preserved by Contractor. ENGINEER shall not. during such visits or as
a result of such observations of Contractor's work in progress, supervise, direct, or have control
over Contractor's work, nor shalt ENGINEER have authority over or responsibility for the
means. methods, techniques, sequences, or procedures of construction selected by Contractor,
for safety precautions and programs incident to Contractor's work. or for any failure of
Contractor to comply with Laws and Regulations applicable to Contractor's fumishing and
performing the Work. Accordingly. ENGINEER neither guarantees the performance of any
Contractor nor assumes responsibility for any Contractor's failure to furnish and perform its
work in accordance with the Contract Documents.
6. (Modified) Defective Work. Recommend to OWNER that Contractor's work be disapproved and
rejected while it is in progress if. on the basis of such observations. ENGINEER believes that such
work will not produce a completed Project that substantially conforms to the Contract Documents or
that it will prejudice the integrity of the design concept of the completed Project as a functioning
whole as indicated in the Contract Documents.
7. Clarifications and lnterpretationr Field Orders Issue necessary clarifications and interpretations of
the Contract Documents as appropriate to the orderly completion of Contractor's work. Such
clarifications and interpretations will be consistent with the intent of and reasonably inferable from
the Contract Documents. ENGINEER may issue Field Orders authorizing minor variations from the
requirements of the Contract Documents.
8. Change Orders and Work Change Directives. Recommend Change Orders and Work Change
Directives to OWNER as appropriate, and prepare Change Orders and Work Change Directives as
required.
9. Shop Drmvings and Samples. Review and approve or take other appropriate action in respect to
Shop Drawings and Samples and other data which Contractor is required to submit, but only for
conformance with the information given in the Contract Documents and compatibility with the
design concept of the completed Project as a functioning whole as indicated in the Contract
Documents. Such reviews and approvals or other action will not extend to means, methods.
techniques, sequences or procedures of construction or to safety precautions and programs incident
thereto. ENGINEER has an obligation to meet any Contractor's submittal schedule that has earlier
been acceptable to ENGINEER.
10. Substitutes and -or-equal. " Evaluate and determine the acceptability of substitute or -or-equal"
materials and equipment proposed by Contractor, but subject to the provisions of paragraph A2.01 of
this Exhibit A.
H. Inspections and Tests. Require such special inspections or tests of Contractor's work as deemed
reasonably necessary, and receive and review all certificates of inspections, tests, and approvals
required by Laws and Regulations or the Contract Documents. ENGINEER's review of such
certificates will be for the purpose of determining that the results certified indicate compliance with
the Contract Documents and will not constitute an independent evaluation that the content or
procedures of such inspections, tee, or approvals comply with the requirements of the Contract
Documents. ENGINEER shall be entitled to rely on the results of such tests.
12. (Modified) Disagreements benreen OWNER and Contractor. Render formal written decisions on all
claims of OWNER and Contractor relating to the acceptability of Contractor's work or the
interpretation of the requirements of the Contract Documents pertaining to the execution and
progress of Contractor's work. In rendering such decisions. ENGINEER shall be fair and not show
partiality to OWNER or Contractor.
Page 6 of 8 Pages
(EXHIBIT A - Scope of Work)
13. Applications for payment. Based on ENGINEER's observations as an experienced and qualified
design professional and on review of Applications for Payment and accompanying supporting
documentation,
a. Determine the amounts that ENGINEER recommends Contractor be paid. Such
recommendations of payment will be in writing and will constitute ENGINEER's representation
to OWNER, based on such observations and review. that, to the best of ENGINEER's
knowledge, information and belief, Contractor's work has progressed to the point indicated the
quality of such work is substantially in accordance with the Contract Documents (subject to an
evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the
results of any subsequent tests called for in the Contract Documents and to any other
qualifications stated in the recommendation). and the conditions precedent to Contractor's being
entitled to such payment appear to have been fulfilled in so far as it is ENGINEER's
responsibility to observe Contractor's work. In the case of unit price work. ENGINEER's
recommendations of payment will include final determinations of quantities and classifications
of Contractor's work (subject to any subsequent adjustments allowed by the Contract
Documents). The responsibilities of ENGINEER contained in paragraph A 1.04.A.5.a are
expressly subject to the limitations set forth in paragraph A1.04.A.S.b and other express or
general limitations in this Agreement and elsewhere.
b. By recommending any payment, ENGINEER shall not thereby be deemed to have represented
that observations made by ENGINEER to check the quality or quantity of Contractor's work as
it is performed and furnished have been exhaustive, extended to every aspect of Contractor's
work in progress. or involved detailed inspections of the Work beyond the responsibilities
specifically assigned to ENGINEER in this Agreement and the Contract Documents. Neither
ENGINEER's review of Contractor's work for the purposes of recommending payments nor
ENGINEER's recommendation of any payment including final payment will impose an
ENGINEER responsibility to supervise, direct, or control Contractor's work in progress or for
the means. methods, techniques, sequences, or procedures of construction or safety precautions
or programs incident thereto, or Contractor's compliance with Laws and Regulations applicable
to Contractor's furnishing and performing the Work. It will also not impose responsibility on
ENGINEER to make any examination to ascertain how or for what purposes Contractor has
used the moneys paid on account of the Contract Price, or to determine that title to any portion
of the work in progress, materials, or equipment has passed to OWNER free and clear of any
liens, claims. security interests. or encumbrances, or that there may not be other matters at issue
between OWNER and Contractor that might afi'ect the amount that should be paid.
14. Contractor's Completion Documents.
a. (Modified) Receive and review maintenance and operating instructions, schedules, and guarantees as
prepared by the Contractor in accordance with the Contract Documents. Engineer will compile this
information as provided by Contractor, and deliver three (3) copies of the same to OWNER.
b. (Modified) Receive bonds, certificates, or other evidence of insurance not previously submitted and
required by the Contract Documents, certificates of inspection. tests and approvals, Shop Drawings,
Samples and other data approved as provided under paragraph A1.04.A.9, and the annotated record
documents which are to be assembled by Contractor in accordance with the Contract Documents to
obtain final payment. The extent of such ENGINEER's review will be limited as provided in
paragraph A 1.04.A.9.
c. ENGINEER shall transmit these documents to OWNER within thirty days of receipt of documents
from Contractor.
d. (Added) Preparing and furnishing to OWNER Record Drawings electronically in a format approved
by the OWNER and on mylar showing appropriate record information based on Project annotated
record documents received from Contractor.
Page 7 of I1 Pages
(EXHIBIT A - Scope of Work)
IS. Substantial Completion. Promptly after notice from Contractor that Contractor considers the entire Work
ready for its intended use. in company with OWNER and Contractor. conduct an inspection to determine
if the Work is Substantially Complete. If after considering any objections of OWNER. ENGINEER
considers the Work Substantially Complete, ENGINEER shall deliver a certificate of Substantial
Completion to OWNER and Contractor.
16. (Modified) Final Notice of .Acceptability of the Work. Conduct a final inspection to determine if the
completed Work of Contractor is acceptable so that ENGINEER may recommend. in writing, final
payment to Contractor. Accompanying the recommendation for final payment. ENGINEER shall also
provide a notice in the forth attached hereto as Exhibit E (the "Notice of Acceptability of work ") that to
the best of ENGINEER's knowledge, information and belief and upon the exercise of ENGINEER'S due
diligence, the Work Is acceptable and is in compliance with the Contract Documents.
B. Duration of Construction Phase. The Construction Phase will commence with the execution of the first
Construction Agreement for the Project or any part thereof and will terminate upon final payment to
Contractors. If the Project involves more than one prime contract as indicated in paragraph A 1.02.C.
Construction Phase services may be rendered at different times in respect to the separate contracts.
C. Limitation of Responsibilities. ENGINEER shall not be responsible for the acts or omissions of any
Contractor, or of any of its subcontractors, suppliers, or of any other individual or entity performing or
furnishing any of the Work. ENGINEER shall not be responsible for failure of any Contractor to perform or
furnish the Work in accordance with the Contract Documents.
A1.05 Surveying and Consullant's Services: Upon written authorization from OWNER. ENGINEER shall perform
or provide the following services
Perform a detailed topographical survey for each street segment identifying the evident rights -of -way.
2. Provide geotechnical services for the project in accordance with applicable requirements of the
OWNER.
3. Provide urban forestry services for the project in accordance with applicable requirements of the
OWNER.
4. Provide SWPPP report services for the project in accordance with applicable requirements of the
OWNER.
PART 2 » ADDITIONAL SERVICES
A2.01 additional Services Requiring OWNER 's Authari ation in daVance
Not Included
A2.02 Required additional Services
Not included
Page 8 of 8 Pages
(EXHIBIT A - Scope of work)
This is EXHIBIT B, consisting of 2 pages, referred to in and
pan of the Agreement between OWNER and ENGINEER
ror Professional Services dated
Initial:
OWNER
ENGINEER
OWNER's Iles nonsi bi lit ies
Article 2 of the Agreenment is amended and supplemented to include the following agrcenment of the parties.
132.01 In addition toother responsibilities of OWNER as set forth in this Agreement, OWNER shall:
A. Provide ENGINEER with all criteria and fill infannation as to OWNER's requirements for the Project.
including design objectives and constraints, space, capacity and performance requirements, flexibility, and
expandability, and any budgetary limitations; and fitmish copies of all design and construction standards which
OWNER will require to be included in the Drawings and Specifications; and fitmish copies of OWNER's standard
fornms, conditions, and related documents for ENGINEER to include in Cite Bidding Documents, when applicable.
13. Furnish to ENGINEER any other available information pertinent to the Project including reports and data
relative to previous designs, or investigation at or adjacent to the Site. Nothing contained in this Exhibit or in this
Agreement shall be construed to require the OWNER to provide such records in any certain formmnt. '['he forntat in
which the existing data and documentation will lie provided shall be at the sole discretion of the OWNER.
C. ( \7odified) Following ENGINEER's assessment of initially - available Project information and data and upon
ENGINEER's written request, furnish or otherwise make available such additional available Project related information
and data as is reasonably required to enable ENGINEER to complete its Basic and Additional Services.
1. (Deleted).
2. (Deleted).
3. (Deleted).
a. (Deleted).
5. (Deleted).
G. (Deleted).
D. (Deleted).
I i. (Modified) Authorize ENGINEER to provide Additional Services as set forth in Par 2 of Exhibit A of the
Agreement as the OWNER determines is necessary.
F. (Modilicd) Arrange for access to and make all provisions liar ENGINEER to enter upon public and private
property as required for ENGINEFR to perfornm services under the Agreement.
(i. Examine all nhernate solutions, studies, reports. sketches. Drawings. Specifications, proposals, and other
documents presented by ENGINFEll (including obtaining advice of an attorney, insurance counselor, and other
advisors or consultants as OWNER deems appropriate with respect to such examination) and render in writing timely
decisions pertaining thereto.
Page 1 of 2 Pages
(Exhibit 11 - OWNEIt's Responsibilities)
H. (Deleted).
1. (Deleted).
J. Advise ENGINEER of the identity and scope of services of any independent consultants employed by
OWNER to perform or furnish services in regard to the Project, including, but not limited to, cost estimating, project
peer review, value engineering, and constructability review.
K. Deleted
L. Deleted
M. Deleted
N. Deleted
Page 2 of 2 Pages
(Exhibit 8 — OWNER's Responsibilities)
''his is EXHIBIT C. consisting of 2 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Payments to ENGINEER for Services and Reimbursable Expenses
Article d of the Agreement is amended and
supplemented to include the following agreement of the
parties:
ARTICLE 4 -- PAYMEN''S''O T IE ENGINEERI
C -1.01 1-or Basic Sen -ices l laving :I Deferminegi
.Scolk ('uvt tut to liviceetl.11ctlu)tl r jl'urntent
Initial:
OWNER
I:NGINEEIt `%
5. 'file portion of the amount billed for
ENGINEER's services will be based upon total
services actually completed during the billing
period, which shall be a calendar month. Invoices
shall be tendered no more o0en than once a month
for all of the services performed during the
applicable month.
A. OWNER shall pay ENGINEER for Basic
Services set forth in Exhibit A is follows: C4.02
L (Modified) A cost not to exceed
amount of $5,11 Q0 based upon the rate schedule,
%%hick is attached as Appendix I of Exhibit C and
incorporated herein liar all intents and purposes.
This amount does not include those ENGINEEWS
C'onsultant's charges as provided below in this
Article d. Subparagraph C -1.05, and %%ill be
distributed at the completion of each of the phase in
the following amount:
a. Preliminary Design S 90,000
b. Final Design Phase 5360.000
c. Bidding and Negotiating Services S 16.000
d. Construction Phase S65,00
2. (Modified) ENGINEER may with the
consent of OWNER alter the distribution of
compensation between individual phases noted
herein to he consistent with services actually
rendered, but shall not exceed Cite total cost not to
exceed amount unless approved in writing by the
OWNER.
3. The cost not to exceed includes
compensation for ENGINEER's services and
services of ENGINFLR's Consultants (with the
exception of those outlined in paragraph C- {.05), if
any. Appropriate amounts have been incorporated
in the cost not to exceed to account for labor.
overhead. ;md profit.
.1. Deleted.
I•'or Ikavic Services 'laving An 0uleterminetl
Sco1k -- Direct Labor Costs Times a Vactor
.lkthutl tf I'tn -ouent
A. (Not Used).
C•1.0:+ l ?ir : l dililioua! .1i rvic c s
A. OWNER shall pay ENGINEER for additional
Services as follows:
L General. For services of ENGINEER's
employees engaged directly on the Project pursuant
to paragraph A2.01 or A2.02 of Exhibit A of the
Agreement, except for services as a consultant or
witness under paragraph A2.01.A.13, an amount
based upon the actual hours worked and the rate
schedule, which is attached as Appendix 1 of
Exhibit C and incorporated herein for all intents and
purposes plus Reimbursable Expenses. Additional
Services shall not be performed without the prior
written consent of the OWNER.
C -1.O4 I•i,r Reiniburvable lirj)envev
A. (Modified) When not included in compensation
for Basic Services tinder paragraph C•1.01. OWNER
shall pay ENGINEER for Reimbursable Expenses
as lite rate set forth in Appendix 2 of this Exhibit C.
Before the OWNER shall be liable for any
reimbursable expenses. the ENGINEER must obtain
prior written approval of the O\1'NI:R of any
expense that exceeds $1,000 for which the
ENGINEER seeks reimbursement. Reimbursable
Page I oft Pages
(Exhibit C - Basic Services With Determined Scope -- Cost not to exceed Method)
Expenses shall not exceed SILOOO without the prior C4.08 Other Provisions Concerning Payment
written consent of the Owner.
B. (Modified) Reimbursable Expenses include
the following categories: mileage, parking tolls, long
distance, reproduction of Drawings, Specifications,
Bidding Documents, and similar Project - related items in
addition to those required under Exhibit A, and, if
authorized in advance by OWNER.
C. The amounts payable to ENGINEER for
Reimbursable Expenses will be the Project - related
internal expenses actually incurred or allocated by
ENGINEER, plus all invoiced external Reimbursable
Expenses allocable to the Project, the latter multiplied by
a Factor of (1.10).
D. Deleted.
E. (Added) The OWNER must approve all travel
expenses before the same are incurred. If such approval
is not obtained, the OWNER shall not be liable for such
travel expenses.
C4.05 For ENGINEER's Consultant's Charges
A. (Modified) Whenever compensation to
ENGINEER herein is stated to include charges of
ENGINEER's Consultants, those charges shall be the
amounts billed by ENGINEER's Consultants to
ENGINEER times a Factor of (1.10-). The consultant
charges shall not exceed the following amounts specified
for each of the following services, unless approved in
writing by the OWNER. The charges include the factor,
and shall not exceed the following without prior written
consent of the OWNER.
(1) Surveying
$57,500
(2) GeotechnicalInvestigation
$15.500
(3) Urban Forestry
$16,000
(4) Environmental Investigation
$11,500
(5) ADA/TAS Compliance
$ 1,800
C4.06 Direct Labor Casts
A. Direct Labor Costs means salaries and wages
paid to ENGINEER's employees but does not include
payroll related costs or benefits.
B. (Deleted).
4.07 Factors
(Deleted)
A. Progress Payments. The portion of the
amounts billed for ENGINEER's services which are
identified in paragraphs C4.01 and C4.03, will be
based on the Direct Labor Costs for the cumulative
hours charged to the Project during the billing
period by all of ENGINEER's employees, plus
Reimbursable Expenses and ENGINEER's
Consultant's charges, if any.
Page 2 of 2 Pages
(Exhibit C - All Other Services/Charges -- Cost not to &coed Method of Payment)
APPENDIX I OF EXHIBIT C — HOURLY RATES
Hourly Rates for Engineering Staff-
All services are to be billed on an hourly basis based on time and materials and based upon the following rates:
Staff Catenory
Billing to
Principal
S 193.00 per hour
Senior Project Manager
$185.00 per hour
Design Manager
$150.00 per hour
Project Engineer
S 145.00 per hour
Engineering Technician
$138.00 per hour
CAD Designer
$I 11.00 per hour
CAD Operator
S 100.00 per hour
Administrative Assistant
S 65.00 per hour
Registered Professional Land Surveyor /Associate
S 156.00 per hour
2 -Man Field Party
S 161.00 per hour
3-Man Field Party
$192.00 per hour
4-Man Field Party
$223.00 per hour
Page I of 1 Pages
(Appendix I of Exhibit C — Hourly Rates)
APPENDIX 2 OF EXHIBIT C — REIMBURSEMENT OF COSTS
Reproduction and Deliveries: Cost plus 10%
Mileage: IRS Rate
Page I of I Pages
(Appendix 2 of Exhibit C — Reimbursement of Costs)
'['his is EXIII131'1' G, consisting of ? pages, referred to in and
part of' the Agreement between OWNER and ENGINEER
for Professional Services dated
Initial:
OWNER
ENGINEER
Insurance
Paragraph 6.05 of the Agreement is amended and supplemented to include the following agreement of the parties.
G6.0i barruance
Throughout the term of this Agreement, the ENGINEER at its own expense shall purchase, maintain and keep in
force and effect insurance against claims for injuries to or death of persons or damages to property which may arise
out of or result from the ENGINEER's operations and/or performance of the work under this Agreement, whether
such operations and/or performance be by the ENGINEER, its agents, representatives, volunteers, employees or
subcontractors or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of
them may be liable.
The ENGINEER's insurance coverage shall be primary insurance with respect to the OWNER, its officers, agents
and employees. Any insurance or self - insurance maintained by the OWNER, its officials, agents and employees
shall be considered in excess of the ENGINEER's insurance and shall not contribute to it. Further, the ENGINEER
shall include all subcontractors as additional insureds under its commercial general liability policies or shall fumish
separate certificates and endorsements for each subcontractor. All coverage for subcontractors shall be subject to all
of the requirements stated herein.
The following is a list of standard insurance policies along with their respective minimum coverage amounts
required in this contract:
Commercial General Liability (CGW
General Aggregate: S1,000,000
Products & Completed Operations: S1,000,000
Personal & Advertising Injury: S1.000.000
Per Occurrence: S500.000
a. Coverage shall be at least as broad as ISO CG 00 01 10 93
b. No coverage shall be excluded from standard Itolicy without notification of individual exclusions being
attached for review and acceptance.
Business Automobile Policy (BAP)
Combined Single Limits: S1,000.000
a. Coverage for "Any Auto."
Workers' Compensation Insurance
Statutory Limits
Employer's Liability S500,000
Waiver of Subrogation required
Errors & Omissions (1i &0)
Limit: S500,000
a. I-or all engineers, and/or design companies.
b. Claints•nradc form is acceptable.
Page I of 2 Pages
(Exhibit G - Insurance)
c. Coverage will be in force for three (3) years after project is completed.
Upon execution of this contract, ENGINEER shall file with the OWNER valid Certificates of Insurance and
endorsements acceptable to the OWNER. Such Certificates shall contain a provision that coverage afforded under
the policies will not be canceled, suspended, voided, or reduced until at least thirty (30) days' prior written notice
has been given to the OWNER via certified mail, return receipt requested.
The ENGINEER shall also file with the OWNER valid Certificates of Insurance covering all subcontractors.
The following are general requirements applicable to all policies:
a. AM Best Rating of B +:V 1I or better.
b. Insurance carriers licensed and admitted to do business in State of Texas will be accepted.
c. Liability policies will be on occurrence form. E & O can be on claims -made form.
d. OWNER, its officers, agents and employees are to be added as Additional Insured to the commercial general
liability and business automobile policies.
c. Upon request of and without cost to OWNER, certified copies of all insurance policies and/or certificates of
insurance shall be furnished to OWNER's representative. Certificates of insurance showing evidence of
insurance coverage shall be provided to OWNER's representative prior to execution of this agreement.
C Upon request of and without cost to OWNER, loss runs (claims listing) of any and/or all insurance coverage
shall be furnished to OWNER's representative.
Page 2 of 2 Pages
(Exhibit G - Insurance)
SI 9NIU33002Id 210 NOLLDV ANV .LV14 L .LN3A3 31.11
NI 'S3I.L2IVd SM33NIJN3 31.1.1. NVI.11 113H.LO NOS113d ANN
JO 3DN391193N 31.11 W021J SlInS321 NO Aft u3SflvO SI
IVH.1 SNOS113d JO 39VIAJV0 A.LH3dONd 2IO'H.LVM 'ANf1I'NI
IVNIOS213d 3141 1NONJ 9NIS111V A1.IrIIEIVI'I 01 '113A3MOH
'Arlddd ION -IIVHS A.LINW3UNl H0f1S '.LN31N33H9t'
SI14 L HIM NOI.L33NN00 Ni NO .30 Ino 9NISI21t'
S.LN31^IAVd 3mdW O.I. S3HflrlmJ aNv `siNmummHJNI
A.L213dOHd 'iWI1331131N1 'S.LHO.L IVNOI.I.N31NII
.S3l.LHVd SM33NION3 311.1. Sty 713M Sd 3DN391193NT
3rlOS 210 .LNIOI' `.L :)nUNOOSILII ri IA1 11M NMO .S311.MVd
S.2133NION3 JO S30N3f1a;ISNO:) 3FI.L 1tIOHJ 213NMO
.L33.L02id UNV AJINW30NI 01. 2133NION3 AG A.LINW3UN1 SI
HdV'd9V21dd SIH.L NI 110J U3UTA02Id A.LINW30NI 31.11..Ld1-I.L
'H3NMO UNV 2133NION3 Illou '013213H S31.LNVc1 3141 JO
N0LLN31N1 a3SS3HdX3 31.11. Sl 11 '(S31LUVd S.2133NION3
Ar13AI.LD31100) 10211N00 S3SIJH3X3 2I33NI9N3 3H.L
HJIHM N3AO AII.LN3 2I31-I.LONv 210 jovumoz) H3(1Nfi
.LNV.L'If1SN00 .LN39V S.2I33NI9N3 3H.1. 210 2133N10N3
3H.L Aft u3.L.LIWIti00 u31rIcldflS HO HO.LOt {H1.NO uns
V Add 01 3UnlIV, -1 110 '1.N3W3MIMN1 A11213d021d
'Ivfl.LD:,m3.LNI '.LHO.L 'ivNOI.LN3.LN1 `30N30I'I03N
JO 1.03 NV H.LIM NOI.L03NN00 NI NO JO If10 ONISIUV
.LN31X3 3H.L 01 .LOVH.LN00 JO I-IOt'MI ANV HOJ NO
A1113dOHd ANV 01 39VWVU 2103 'NOS213d ANV 30 HIV30
NO 01 AHfIrNl HOJ 'S33J S.A3N21011V GNIV 'S.LSOO .LHfl00
'NOI.LV91.LIrl JO S3SN3clX3 TIT JNlafl'IONI 'UNIN AH3A3
30 A.LI'IIUVlrl uNd S.LIf1S `N011.Od 30 S3Sflt'O 'S30vIAivu
`S3SSOr1 `SWIVrIO rIrIV UNV ANV .LSNIV9V UNV WONJ,
(..2I3NM0,, SV O.L a3212I3J:l121 113.LJtr3213H) S33AOrlcIW3 UNV
'S.LN39d `SH30IJJ0 S.LI 'H3NMO UN3J3a UNV SS3rIWHV1-I
Q'IOH GNV AJINW3UN1 rlrlVI-IS GNV O.L S33H9V H33NION3
uollcau!unlapul
��j✓�/ ?Icicl \I7 \.1
IVINANO
:leiuu I
palup ltsuolssaloid
j"i 2133NMN3 Put: )13\ NO uaaAwq Ioauwa.il. %, aip
_lo ued pue ui oI p.).ui u 'saed Z o hiisisoi •M .1.111111 \ :a %I "1111,
BROUGHT AGAINST THE OWNER FROM WHICH THE
OWNER IS INDEMNIFIED, ENGINEER FURTHER AGREES AND
COVENANTS TO DEFEND THE ACTION OR PROCEEDING BY
LEGAL COUNSEL ACCEPTABLE TO THE OWNER. THE
INDEMNITY PROVIDED HEREINABOVE SHALL SURVIVE THE
TERMINATION AND /OR EXPIRATION OF THIS AGREEMENT.
By this Agreement, the OWNER does not consent to litigation or suit, and the OWNER
hereby expressly revokes any consent to litigation that it may have granted by the terms
of this Contract or any other contract or agreement, any charter, or applicable state law.
Nothing herein shall be construed so as to limit or waive OWNER'S sovereign
immunity. ENGINEER assumes full responsibility for its work performed hereunder
and hereby releases, relinquishes and discharges OWNER, its officers, agents, and
employees from all claims, demands, and causes of action of every kind and character
for any injury to or death of any person and /or any loss of or damage to any property
that is caused by or alleged to be caused by, arising out of, or in connection with
ENGINEER's work to be performed hereunder. This release shall apply with respect to
ENGINEEWs, work regardless of whether said claims, demands, and causes of action
are covered in whole or in part by insurance.
The protections afforded to OWNER in this Exhibit K shall control and supersede
any apportionment of liability or release of liability contained elsewhere in the
Contract Documents. Furthermore, the provisions contained in this Exhibit "K"
shall survive the termination and/or expiration of this Agreement.
S:�STARS%PUBLICWORKS%StaMDavel tamilton% Baytown% Contact& WFWWTPofisitescwcf %PEReontmclNEW WFPoRsitccu08054t.doe