Ordinance No. 14,019ORDINANCE NO. 14,019
AN ORDINANCE OF THE CITY COUNCIL OF THE CITY OF BAYTOWN, TEXAS,
AUTHORIZING A PROFESSIONAL SERVICES AGREEMENT WITH KIMLEY-
HORN AND ASSOCIATES, INC., FOR THE GOOSE CREEK LIFT STATION
PROJECT; AUTHORIZING PAYMENT BY THE CITY OF BAYTOWN IN AN
AMOUNT NOT TO EXCEED FOUR HUNDRED SIXTY-FIVE THOUSAND AND
NO 100 DOLLARS ($465,000.00); MAKING OTHER PROVISIONS RELATED
THERETO; AND PROVIDING FOR THE EFFECTIVE DATE THEREOF.
*************************************************************************************
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF BAYTOWN, TEXAS:
Section 1: That the City Council of the City of Baytown, Texas, hereby authorizes and
directs the City Manager to execute and the City Clerk to attest to a Professional Services Agreement with
Kimley-Horn and Associates, Inc., for the Goose Creek Lift Station Project. A copy of said agreement is
attached hereto as Exhibit "A" and incorporated herein for all intents and purposes.
Section 2: That the City Council of the City of Baytown authorizes payment to Kimley-
Hom and Associates, Inc., in an amount not to exceed FOUR HUNDRED SIXTY-FIVE THOUSAND
AND N0/100 DOLLARS ($465,000.00) for professional services in accordance with the agreement
authorized in Section 1 hereinabove.
Section 3: That the City Manager is hereby granted general authority to approve a decrease
or an increase in costs by FIFTY THOUSAND AND NO/100 DOLLARS ($50,000.00) or less, provided
that the amount authorized in Section 2 hereof may not be increased by more than twenty-five percent
(25%).
Section 4: This ordinance shall take effect immediately from and after its passage by the
City Council of the City of Baytown.
INTRODUCED, READ and PASSED by the affirmative vote of the City Council of the City of
Baytown this the 28"' day of February, 2019.
BRANDON CAPETILLO, Mayor
ATT
L ICIA BRYSCH, City erk
APPROVED AS TO FORM:
I NACIO RAMIREZ, SR., City A orney
`.COBFSO 1 � Legal\Karen\Files •.City Council\Ordinances\2019\February 28\KimleyHomAgreement4GooseCreekLiftStationProject. doc
Exhibit "A"
STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
THIS AGREEMENT effective as of the day of , 2019 ("Effective Date").
Between
City of Baytown ("OWNER")
and
Kimley-Horn and Associates, Inc. ("ENGINEER")
OWNER intends to contract with ENGINEER for professional engineering services, including preliminary
engineering, final design, bid phase services, and construction phase services for the rehabilitation of the Goose
Creek Lift Station (the "Project"). The scope of services is divided into the following primary tasks:
1. Supporting Design Information for Goose Creek Lift Station
2. Goose Creek Lift Station Preliminary Engineering Report (PER)
3. Goose Creek Lift Station Final Design, Bid Phase, and Construction Phase Services
The Project includes a PER containing the analysis of the existing lift station, recommending two options for
replacement of the existing wet well to the OWNER with associated design calculations, conversion of the pumping
system from dry pit/wet pit self -priming pump set up to a submersible pump set up, raising the electrical equipment
two (2) feet above the FEMA 500 -year base flood elevation per Harris County requirements, preparing construction
plans and specifications for the lift station, and providing bid phase and construction phase services for the lift
station design.
OWNER and ENGINEER in consideration of their mutual covenants as set forth herein agree as follows:
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 1 of 12
TABLE OF CONTENTS Page
ARTICLE 1 - SERVICES OF ENGINEER........................................................................................................................ 3
1.01 Scope................................................................................................................................................................. 3
ARTICLE 2 - OWNER'S RESPONSIBILITIES................................................................................................................. 3
2.01 General............................................................................................................................................................... 3
ARTICLE 3 - TIMES FOR RENDERING SERVICES...................................................................................................... 3
3.01 General............................................................................................................................................................... 3
3.02 Suspension......................................................................................................................................................... 3
ARTICLE 4 - PAYMENTS TO ENGINEER...................................................................................................................... 3
4.01 Methods of Payment for Services and Reimbursable Expenses of ENGINEER ............................................. 3
4.02 Other Provisions Concerning Payments............................................................................................................ 3
ARTICLE 5 - OPINIONS OF COST................................................................................................................................... 4
5.01 Opinions of Probable Construction Cost.......................................................................................................... 4
5.02 Designing to Construction Cost Limit.............................................................................................................. 4
5.03 Opinions of Total Project Costs....................................................................................................................... 4
ARTICLE 6 - GENERAL CONSIDERATIONS................................................................................................................. 4
6.01 Standards of Performance................................................................................................................................. 4
6.02 Authorized Project Representatives.................................................................................................................. 5
6.03 Design without Construction Phase Services.................................................................................................... 5
6.04 Use of Documents............................................................................................................................................. 6
6.05 Insurance............................................................................................................................................................ 6
6.06 Termination....................................................................................................................................................... 6
6.07 Controlling Law................................................................................................................................................. 7
6.08 Successors, Assigns, and Beneficiaries............................................................................................................. 7
6.09 Dispute Resolution............................................................................................................................................ 7
6.10 Hazardous Environmental Condition................................................................................................................ 7
6.11 Allocation of Risks............................................................................................................................................ 8
6.12 Notices............................................................................................................................................................... 8
6.13 Survival.............................................................................................................................................................. 8
6.14 Severability........................................................................................................................................................ 8
6.15 Waiver............................................................................................................................................................... 8
6.16 Headings............................................................................................................................................................ 8
ARTICLE7 - DEFINITIONS.............................................................................................................................................. 8
7.01 Defined Terms.................................................................................................................................................. 8
ARTICLE 8 - EXHIBITS AND SPECIAL PROVISIONS............................................................................................... 11
8.01 Exhibits Included............................................................................................................................................. 11
8.02 Total Agreement.............................................................................................................................................. 11
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 2 of 12
ARTICLE 1- SERVICES OF ENGINEER
1.01 Scope
A. ENGINEER, as an independent contractor, shall
provide the Basic and Additional Services set forth herein and
in Exhibit A.
contributes to the delay or suspension, ENGINEER shall have
no right to seek additional compensation.
ARTICLE 4 - PAYMENTS TO ENGINEER
4.01 Methods of Payment for Services and
Reimbursable Expenses of ENGINEER
B. (Modified). Upon issuance of a notice to proceed by A. For Basic Services. OWNER shall pay ENGINEER
the OWNER, ENGINEER is authorized to begin Basic for Basic Services performed or furnished under Exhibit A,
Services as set forth in Exhibit A. Part 1, as set forth in Exhibit C.
C. (Deleted).
ARTICLE 2 - OWNER'S RESPONSIBILITIES
2.01 General
A. OWNER shall have the responsibilities set forth
herein and in Exhibit B.
ARTICLE 3 - TIMES FOR RENDERING SERVICES
3.01 General
A. (Modified). ENGINEER's services and
compensation under this Agreement have been agreed to for
the services specified in Exhibit A. ENGINEER's obligation
to render services hereunder will be for whatever period
necessary for the final completion of said services.
B. (Deleted).
C. (Modified). For purposes of this Agreement the term
"day" means a calendar day of 24 hours.
3.02 Suspension
A. (Deleted).
B. (Modified). If ENGINEER's services are delayed or
suspended in whole or in part by OWNER, ENGINEER may
be entitled to equitable adjustment of rates and amounts of
compensation provided for elsewhere in this Agreement to
reflect, reasonable costs incurred by ENGINEER in
connection with among other things, such delay or suspension
and reactivation and the fact that the time for performance
under this Agreement has been revised, unless such delay or
suspension is caused in whole or in part by ENGINEER, its
officers, agents, or employees. If ENGINEER causes or
B. For Additional Services. OWNER shall pay
ENGINEER for Additional Services performed or furnished
under Exhibit A, Part 2, as set forth in Exhibit C.
C. (Modified). For Reimbursable Expenses. In
addition to payments provided for in paragraphs 4.01.A and
4.01.13, OWNER shall pay ENGINEER for Reimbursable
Expenses incurred by ENGINEER and ENGINEER's
Consultants as set forth in Exhibit C. However, all expenses
associated with meals and lodging must be approved in
writing by OWNER prior to ENGINEER incurring any
expense associated therewith; otherwise, the parties hereto
agree and understand that OWNER shall not be liable and
ENGINEER shall not make a claim against OWNER for any
such expenses.
4.02 Other Provisions Concerning Payments
A. Preparation of Invoices. Invoices will be prepared
in accordance with OWNER's standard processing practices
and will be submitted to OWNER monthly by ENGINEER,
unless otherwise agreed. ENGINEER shall supply detailed
back-up information along with each invoice in order for the
OWNER to effectively evaluate the fees and charges. The
amount billed in each invoice will be calculated as set forth in
Exhibit C. Invoices shall be received by the OWNER not
later than sixty calendar (60) days from the date ENGINEER
and/or its subconsultants perform the services or incur the
expense. Failure by ENGINEER to comply with the
requirements herein in a timely manner with this requirement
shall result in ENGINEER'S invoice being denied.
B. (Modified). Payment of Invoices. Invoices are due
and payable within 30 calendar days after the receipt of the
invoice and the necessary backup information. If OWNER
fails to make any payment due ENGINEER for services and
expenses within 30 calendar days after receipt of
ENGINEER's invoice and the required backup documentation
therefor, the amounts due ENGINEER will accrue interest at
the rate set forth in Section 2251.025 of the Texas
Government Code (or the maximum rate of interest permitted
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 3 of 12
by law, if less) after the 30th calendar day. ENGINEER may
after giving seven calendar days' written notice to OWNER
suspend services under this Agreement until ENGINEER has
been paid in full all amounts due for services, expenses, and
other related charges. However, it is expressly understood and
agreed that ENGINEER will not charge any interest or penalty
as set forth herein on any portion of an invoice that is disputed
and/or withheld in accordance with paragraph 4.02 and that
ENGINEER will not suspend services under the agreement on
account of a disputed invoice or on account of monies
withheld. All payments will be credited first to principal and
then to interest.
C. Disputed Invoices. In the event of a disputed or
contested invoice, only that portion so contested may be
withheld from payment, and the undisputed portion will be
paid.
D. Payments Upon Termination. In the event of any
termination under section 6.06, ENGINEER will be entitled to
invoice OWNER and will be paid in accordance with Exhibit
C for all services performed or furnished and all Reimbursable
Expenses incurred through the effective date of termination
provided all instruments of service have been tendered to the
OWNER.
2. (Deleted).
E. (Modified). Records of ENGINEER's Costs.
Records of ENGINEER's costs pertinent to ENGINEER's
compensation under this Agreement shall be kept in
accordance with generally accepted accounting practices.
Copies of such records will be made available to OWNER
upon request at no cost to OWNER.
F. Legislative Actions. In the event of legislative
actions after the Effective Date of the Agreement by any level
of government that impose taxes, fees, or costs on
ENGINEER's services or other costs in connection with this
Project or compensation therefor, such new taxes, fees, or
costs shall be invoiced to and paid by OWNER as a
Reimbursable Expense to which a Factor of 1.0 shall be
applied. Should such taxes, fees, or costs be imposed, they
shall be in addition to ENGINEER's estimated total
compensation.
G. (Added). Indebtedness. If ENGINEER, at any time
during the term of this agreement, incurs a debt, as the word
is defined in section 2-662 of the Code of Ordinances of the
City of Baytown, it shall immediately notify the OWNER's
Director of Finance in writing. If the OWNER's Director of
Finance becomes aware that ENGINEER has incurred a
debt, the OWNER's Director of Finance shall immediately
notify ENGINEER in writing. If ENGINEER does not pay
the debt within 30 days of either such notification, the
OWNER's Director of Finance may deduct funds in an
amount equal to the debt from any payments owed to
ENGINEER under this Agreement, and ENGINEER waives
any recourse therefor.
ARTICLE 5 - OPINIONS OF COST
5.01 Opinions of Probable Construction Cost
A. ENGINEER's opinions of probable Construction
Cost provided for herein are to be made on the basis of
ENGINEER's experience and qualifications and represent
ENGINEER's best judgment as an experienced and qualified
professional generally familiar with the industry. However,
since ENGINEER has no control over the cost of labor,
materials, equipment, or services furnished by others, or over
the Contractor's methods of determining prices, or over
competitive bidding or market conditions, ENGINEER cannot
and does not guarantee that proposals, bids, or actual
Construction Cost will not vary from opinions of probable
Construction Cost prepared by ENGINEER. If OWNER
wishes greater assurance as to probable Construction Cost,
OWNER shall employ an independent cost estimator as
provided in Exhibit B.
5.02 Designing to Construction Cost Limit
A. (Deleted).
5.03 Opinions of Total Project Costs
A. (Deleted).
ARTICLE 6 - GENERAL CONSIDERATIONS
6.01 Standards of Performance
A. (Modified). The standard of care for all professional
engineering and related services performed or furnished by
ENGINEER under this Agreement will be the care and skill
ordinarily used by persons performing the applicable
disciplines, including, but not limited to, surveyors and
professional engineers, practicing under similar circumstances
at the same time and in the same locality.
B. (Modified). All professionals performing services
under this Agreement shall be responsible for the technical
accuracy of their services, and OWNER shall not be
responsible for discovering deficiencies therein. ENGINEER
shall correct such deficiencies without additional
compensation except to the extent such action is directly
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 4 of 12
attributable to deficiencies in OWNER -furnished information
upon which ENGINEER is authorized to rely as provided in
Section 6.01.E.
C. ENGINEER shall perform or famish professional
engineering and related services in all phases of the Project to
which this Agreement applies. ENGINEER shall serve as
OWNER's prime professional for the Project. Such
professionals shall be appropriately licensed and/or registered
to practice in the State of Texas. ENGINEER may employ
such ENGINEER's Consultants as ENGINEER deems
necessary to assist in the performance or furnishing of the
services. ENGINEER shall not be required to employ any
ENGINEER's Consultant unacceptable to ENGINEER.
D. ENGINEER and OWNER shall comply with
applicable Laws or Regulations and OWNER -mandated
standards. This Agreement is based on these requirements as
of its Effective Date. Changes to these requirements after the
Effective Date of this Agreement may be the basis for
modifications to OWNER's responsibilities or to
ENGINEER's scope of services, times of performance, or
compensation.
E. (Modified). OWNER shall be responsible for, and
ENGINEER may rely upon, the accuracy and completeness of
all requirements, programs, instructions, reports, data, and
other information furnished by OWNER to ENGINEER
pursuant to this Agreement, unless expressly stated or
communicated otherwise by OWNER. ENGINEER may use
such requirements, reports, data, and information in
performing or furnishing services under this Agreement.
F. OWNER shall make decisions and carry out its other
responsibilities in a timely manner and shall bear all costs
incident thereto so as not to delay the services of ENGINEER
G. Prior to the commencement of the Construction
Phase, OWNER shall notify ENGINEER of any variations
from the language indicated in Exhibit E, "Notice of
Acceptability of Work," or of any other notice or certification
that ENGINEER will be requested to provide to OWNER or
third parties in connection with the Project. OWNER and
ENGINEER shall reach agreement on the terms of any such
requested notice or certification, and OWNER shall authorize
such Additional Services as are necessary to enable
ENGINEER to provide the notices or certifications requested.
H. (Modified). ENGINEER shall not be required to sign
any documents, no matter by whom requested, that would
result in ENGINEER's having to certify, guarantee or warrant
the existence of conditions whose existence ENGINEER
cannot ascertain; provided, that ENGINEER has exercised
due diligence and was not otherwise required to certify,
guarantee or warrant the existence of such conditions.
I. During the Construction Phase, ENGINEER shall
not supervise, direct, or have control over Contractor's work,
nor shall ENGINEER have authority over or responsibility for
the means, methods, techniques, sequences, or procedures of
construction selected by Contractor, for safety precautions and
programs incident to the Contractor's work in progress, nor
for any failure of Contractor to comply with Laws and
Regulations applicable to Contractor's furnishing and
performing the Work.
J. (Modified). ENGINEER neither guarantees the
performance of any Contractor nor assumes responsibility for
any Contractor's failure to furnish and perform the Work in
accordance with the Contract Documents. However, nothing
contained in this paragraph shall be construed so as to absolve
ENGINEER from liability for any such failure about which
ENGINEER knew or should have known existed in the
exercise of ENGINEER's services under this Agreement.
K. (Modified). ENGINEER shall not be responsible for
the acts or omissions of any Contractor(s), subcontractor or
supplier, or of any of the Contractor's agents or employees or
any other persons (except ENGINEER's own employees and
its consultants for which it is legally liable) at the Site or
otherwise furnishing or performing any of the Contractor's
work; or for any decision made on interpretations or
clarifications of the Contract Documents given by OWNER
without consultation and advice of ENGINEER
L. (Modified). The General Conditions for any
construction contract documents prepared hereunder are to be
the Standard Form of Agreement between Owner and
Contractor and as approved by OWNER in writing.
6.02 Authorized Project Representatives
A. Contemporaneous with the execution of this
Agreement, ENGINEER and OWNER shall designate
specific individuals to act as ENGINEER's and OWNER's
representatives with respect to the services to be performed or
furnished by ENGINEER and responsibilities of OWNER
under this Agreement. Such individuals shall have authority
to transmit instructions, receive information, and render
decisions relative to the Project on behalf of each respective
ply.
6.03 Design without Construction Phase Services
(Deleted).
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 5 of 12
6.04 Use of Documents
A. (Modified). Upon execution of this Agreement,
ENGINEER grants to the OWNER an ownership interest in
the Instruments of Service. ENGINEER shall obtain similar
interests from ENGINEER's consultants consistent with this
Agreement. Within seven days of any termination or
expiration of this Agreement, ENGINEER shall be required to
tender to OWNER all Instruments of Service; provided
OWNER has paid all monies, excluding any disputed amount,
due and owing to ENGINEER in accordance with this
Agreement. With such ownership interest, it is expressly
understood by the parties hereto that the OWNER may use the
Instruments of Service for any purposes which the OWNER
sees fit, including, but not limited to, subsequent construction,
reconstruction, alteration, and/or repairs of the Project. As a
condition to the OWNER's use of the Instruments of Service,
the OWNER hereby expressly agrees to remove
ENGINEER's name and all references to ENGINEER, and its
consultants from the Documents. The OWNER hereby
releases any and all claims which the OWNER could make
arising out of or in connection with any reuse of the
documents by the OWNER This release of claims for the
matters covered in this Paragraph 6.04.A shall be for the
benefit of ENGINEER, its officers, and employees and sub -
consultants, as well as their successors and assigns.
B. (Modified). Copies of OWNER -furnished data that
may be relied upon by ENGINEER are limited to the printed
copies that are delivered to ENGINEER pursuant to Exhibit B
unless otherwise expressly stated or communicated by
OWNER. Files in electronic media format of text, data,
graphics, or of other types that are furnished by OWNER to
ENGINEER are only for convenience of ENGINEER. Any
conclusion or information obtained or derived from such
electronic files will be at the user's sole risk.
C. Copies of Documents that may be relied upon by
OWNER are limited to the printed copies (also known as hard
copies) that are signed or sealed by the appropriate
professional. Files in electronic media format of text, data,
graphics, or of other types that are furnished by ENGINEER
to OWNER are only for convenience of OWNER. Any
conclusion or information obtained or derived from such
electronic files will be at the user's sole risk.
D. Because data stored in electronic media format can
deteriorate or be modified inadvertently or otherwise without
authorization of the data's creator, the party receiving
electronic files agrees that it will perform acceptance tests or
procedures within 60 calendar days, after which the receiving
party shall be deemed to have accepted the data thus
transferred. The party delivering the electronic files will
correct any errors detected within the 60 -day acceptance
period. ENGINEER shall not be responsible to maintain
documents stored in electronic media format after acceptance
by OWNER-
E.
WNER
E. When transferring documents in electronic media
format, ENGINEER makes no representations as to long-term
compatibility, usability, or readability of documents resulting
from the use of software application packages, operating
systems, or computer hardware differing from those used by
ENGINEER at the beginning of this Project.
F. (Modified). Any use of the Documents on any
extension of the Project or on any other project shall be at
OWNER's sole risk and OWNER hereby releases
ENGINEER from any liability associated solely with the reuse
of the Documents.
G. If there is a discrepancy between the electronic files
and the hard copies, the hard copies govern.
H. Any verification or adaptation of the Documents for
extensions of the Project or for any other project will entitle
ENGINEER to further compensation at rates to be agreed
upon by OWNER and ENGINEER.
6.05 Insurance
A. ENGINEER shall procure and maintain insurance as
set forth in Exhibit G, "Insurance."
B. Not used.
C. Not used.
D. Not used.
E. Not used.
F. At any time, OWNER may request that ENGINEER,
at OWNER's sole expense, provide additional insurance
coverage, increased limits, or revised deductibles that are
more protective than those specified in Exhibit G. If so
requested by OWNER, with the concurrence of ENGINEER,
and if commercially available, ENGINEER shall obtain and
shall require ENGINEER's Consultants to obtain such
additional insurance coverage, different limits, or revised
deductibles for such periods of time as requested by OWNER,
and Exhibit G will be supplemented to incorporate these
requirements.
6.06 Termination
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 6 of 12
A. (Modified). The obligations hereunder may be
terminated:
1. For cause,
a. (Modified). By either party upon 30
calendar days written notice in the event of failure by
the other party to perform in accordance with the
terms hereof through no fault of the terminating
party; or
b. By ENGINEER upon seven calendar days'
written notice if ENGINEER is being requested by
OWNER to furnish or perform services contrary to
ENGINEER's responsibility as a licensed
professional.
c. Notwithstanding the foregoing, this
Agreement will not terminate as a result of such
substantial failure if the party receiving such notice
begins, within seven calendar days of receipt of such
notice, to correct its failure to perform and proceeds
diligently to cure such failure within no more than 30
calendar days of receipt thereof; provided, however,
that if and to the extent such substantial failure
cannot be reasonably cured within such 30 calendar
day period, and if such party has diligently attempted
to cure the same and thereafter continues diligently
to cure the same then the cure period provided for
herein shall extend up to, but in no case more than 60
calendar days after the date of receipt of the notice.
B. Neither OWNER nor ENGINEER may assign,
sublet, or transfer any rights under or interest (including, but
without limitation, moneys that are due or may become due) in
this Agreement without the written consent of the other,
except to the extent that any assignment, subletting, or transfer
is mandated or restricted by law. Unless specifically stated to
the contrary in any written consent to an assignment, no
assignment will release or discharge the assignor from any
duty or responsibility under this Agreement.
C. Unless expressly provided otherwise in this
Agreement:
1. Nothing in this Agreement shall be construed to
create, impose, or give rise to any duty owed by OWNER
or ENGINEER to any Contractor, Contractor's
subcontractor, supplier, other individual or entity, or to
any surety for or employee of any of them.
2. All duties and responsibilities undertaken
pursuant to this Agreement will be for the sole and
exclusive benefit of OWNER and ENGINEER and not
for the benefit of any other party. The OWNER agrees
that the substance of the provisions of this paragraph
6.08.0 shall appear in the Contract Documents.
6.09 Not Used.
6.10 Hazardous Environmental Condition
A. OWNER represents to ENGINEER that to the best
2. For convenience by OWNER effective upon the of its knowledge a Hazardous Environmental Condition does
receipt of notice by ENGINEER. not exist.
B. Not used.
6.07 Controlling Law
A. This Agreement is to be governed by the law of the
state in which the Project is located. Venue for all purposes
shall be in Harris County, Texas.
6.08 Successors, Assigns, and Beneficiaries
A. OWNER and ENGINEER each is hereby bound and
the partners, successors, executors, administrators and legal
representatives of OWNER and ENGINEER (and to the
extent permitted by paragraph 6.083 the assigns of OWNER
and ENGINEER) are hereby bound to the other party to this
Agreement and to the partners, successors, executors,
administrators and legal representatives (and said assigns) of
such other party, in respect of all covenants, agreements and
obligations of this Agreement.
B. (Modified). OWNER has disclosed to the best of
its knowledge and belief to ENGINEER the existence of all
Asbestos, PCB's, Petroleum, Hazardous Waste, or
Radioactive Material located at or near the Site, including
type, quantity and location.
C. (Modified). If a Hazardous Environmental
Condition is encountered or alleged, ENGINEER shall have
the obligation to notify OWNER on or before the next
business day of the same.
D. It is acknowledged by both parties that
ENGINEER's scope of services does not include any services
related to a Hazardous Environmental Condition. In the event
ENGINEER or any other party encounters a Hazardous
Environmental Condition, ENGINEER may, at its option and
without liability for consequential or any other damages,
suspend performance of services on the portion of the Project
affected thereby until OWNER: (i) retains appropriate
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 7 of 12
specialist consultant(s) or contractor(s) to identify and, as
appropriate, abate, remediate, or remove the Hazardous
Environmental Condition; and (ii) wan -ants that the Site is in
full compliance with applicable Laws and Regulations.
E. OWNER acknowledges that ENGINEER is
performing professional services for OWNER and that
ENGINEER is not and shall not be required to become an
"arranger," "operator," "generator," or "transporter" of
hazardous substances, as defined in the Comprehensive
Environmental Response, Compensation, and Liability Act of
1990 (CERCLA), which are or may be encountered at or near
the Site in connection with ENGINEER's activities under this
Agreement.
F. If ENGINEER's services under this Agreement
cannot be performed because of a Hazardous Environmental
Condition, the existence of the condition shall justify
ENGINEER's terminating this Agreement for cause on 30
calendar days' notice.
6.11 Allocation of Risks
A. (Modified). Indemnification. See Exhibit K.
B. (Added). Notwithstanding anything to the contrary
contained in this Agreement, the OWNER and ENGINEER
hereby agree that no claim or dispute between the OWNER
and ENGINEER arising out of or relating to this Agreement
shall be decided by any arbitration proceeding including,
without limitation, any proceeding under the Federal
Arbitration Act (9 U.S.C. Sections 1-14), or any applicable
State arbitration statute, including, but not limited to, the
Texas General Arbitration Act, provided that in the event
that the OWNER is subjected to an arbitration proceeding
notwithstanding this provision, ENGINEER consents to be
joined in the arbitration proceeding if ENGINEER'S
presence is required or requested by the OWNER for
complete relief to be recorded in the arbitration proceeding.
6.12 Notices
A. (Modified). Any notice required under this
Agreement will be in writing, addressed to the appropriate
party at its address on the signature page and given personally,
or by registered or certified mail postage prepaid, or by a
commercial courier service. Additionally, notices may be
given via facsimile or by electronic mail if such notice is also
given personally, or by registered or certified mail or by a
commercial courier service. All notices shall be effective
upon the date of receipt.
6.13 Survival
A. (Modified). All express representations,
indemnifications, and limitations of liability included in this
Agreement will survive its completion or termination for any
reason.
6.14 Severability
A. Any provision or part of the Agreement held to be
void or unenforceable under any Laws or Regulations shall be
deemed stricken, and all remaining provisions shall continue
to be valid and binding upon OWNER and ENGINEER, who
agree that the Agreement shall be reformed to replace such
stricken provision or part thereof with a valid and enforceable
provision that comes as close as possible to expressing the
intention of the stricken provision.
6.15 Waiver
A. Non -enforcement of any provision by either party
shall not constitute a waiver of that provision, nor shall it
affect the enforceability of that provision or of the remainder
of this Agreement.
6.16 Headings
A. The headings used in this Agreement are for general
reference only and do not have special significance.
ARTICLE 7 - DEFINITIONS
7.01 Defined Terms
A. Wherever used in this Agreement (including the
Exhibits hereto) and printed with initial or all capital letters,
the terms listed below have the meanings indicated, which
are applicable to both the singular and plural thereof:
1. Addenda—Written or graphic instruments issued
prior to the opening of Bids which clarify, correct, or change
the Bidding Documents.
2. Additional Services—The services to be performed
for or furnished to OWNER by ENGINEER in accordance
with Exhibit A, Part 2 of this Agreement.
3. Agreement --This "Standard Form of Agreement
between OWNER and ENGINEER for Professional
Services," including those Exhibits listed in Article 8 hereof.
4. Application for Payment—The form acceptable to
ENGINEER which is to be used by Contractor in requesting
progress or final payments for the completion of its Work and
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 8of12
which is to be accompanied by such supporting
documentation as is required by the Contract Documents.
5. Asbestos—Any material that contains more than one
percent asbestos and is friable or is releasing asbestos fibers
into the air above current action levels established by the
United States Occupational Safety and Health Administration.
6. Basic Services—The services to be performed for or
furnished to OWNER by ENGINEER in accordance with
Exhibit A, Part 1, of this Agreement.
7. Bid—The offer or proposal of the bidder submitted
on the prescribed form setting forth the prices for the Work to
be performed.
8. Bidding Documents—The advertisement or invitation
to Bid, instructions to bidders, the Bid form and attachments,
the Bid bond, if any, the proposed Contract Documents, and
all Addenda, if any.
9. Change Order—A document recommended by
ENGINEER, which is signed by Contractor and OWNER to
authorize an addition, deletion or revision in the Work, or an
adjustment in the Contract Price or the Contract Times, issued
on or after the Effective Date of the Construction Agreement.
10. Construction Agreement—The written instrument
which is evidence of the agreement, contained in the Contract
Documents, between OWNER and Contractor covering the
Work.
11. Construction Contract—The entire and integrated
written agreement between the OWNER and Contractor
concerning the Work.
12. Construction Cost—The cost to OWNER of those
portions of the entire Project designed or specified by
ENGINEER. Construction Cost does not include costs of
services of ENGINEER or other design professionals and
consultants, cost of land, rights-of-way, or compensation for
damages to properties, or OWNER's costs for legal,
accounting, insurance counseling or auditing services, or
interest and financing charges incurred in connection with the
Project, or the cost of other services to be provided by others
to OWNER pursuant to Exhibit B of this Agreement.
Construction Cost is one of the items comprising Total Project
Costs.
13. (Modified). Contract Documents—Documents that
establish the rights and obligations of the parties engaged in
construction and include the Construction Agreement between
OWNER and Contractor and all documents referenced
therein, Addenda (which pertain to the Contract Documents),
Contractor's Bid (including documentation accompanying the
Bid and any post -Bid documentation submitted prior to the
notice of award) when attached as an exhibit to the
Construction Agreement, the notice to proceed, the bonds,
appropriate certifications, insurance documents the General
Conditions, the Supplementary Conditions, the Specifications
and the Drawings as the same are more specifically identified
in the Construction Agreement, together with all Written
Amendments, Change Orders, Work Change Directives, Field
Orders, and ENGINEER's written interpretations and
clarifications issued on or after the Effective Date of the
Construction Agreement. Approved Shop Drawings and the
reports and drawings of subsurface and physical conditions
are not Contract Documents.
14. Contract Price—The monies payable by OWNER to
Contractor for completion of the Work in accordance with the
Contract Documents and as stated in the Construction
Agreement.
15. Contract limes—The numbers of calendar days or
the dates stated in the Construction Agreement to: (i) achieve
Final Completion, and (ii) complete the Work so that it is
ready for final payment as evidenced by ENGINEER's written
recommendation of final payment.
16. Contractor—An individual or entity with whom
OWNER enters into a Construction Agreement.
17. Correction Period—The time after Final Completion
during which Contractor must correct, at no cost to OWNER,
any Defective Work, normally one year after the date of Final
Completion or such longer period of time as may be
prescribed by Laws or Regulations or by the terms of any
applicable special guarantee or specific provision of the
Contract Documents.
18. Defective—An adjective which, when modifying the
word Work, refers to Work that is unsatisfactory, faulty, or
deficient, in that it does not conform to the Contract
Documents, or does not meet the requirements of any
inspection, reference standard, test, or approval referred to in
the Contract Documents, or has been damaged prior to
ENGINEEWs recommendation of final payment.
19. Documents—Data, reports, Drawings, Specifications,
Record Drawings, and other deliverables, whether in printed
or electronic media format, provided or furnished in
appropriate phases by ENGINEER to OWNER pursuant to
this Agreement.
20. Drawings—That part of the Contract Documents
prepared or approved by ENGINEER which graphically
shows the scope, extent, and character of the Work to be
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 9 of 12
performed by Contractor. Shop Drawings are not Drawings as
so defined.
21. Effective Date of the Construction Agreement—The
date indicated in the Construction Agreement on which it
becomes effective, but if no such date is indicated, it means
the date on which the Construction Agreement is signed and
delivered by the last of the two parties to sign and deliver.
22. Effective Date of the Agreement—The date indicated
in this Agreement on which it becomes effective, but if no
such date is indicated, it means the date on which the
Agreement is signed and delivered by the last of the two
parties to sign and deliver.
23. ENGINEER's Consultants or Consultants—
Individuals or entities having a contract with ENGINEER to
famish services with respect to this Project as ENGINEER's
independent professional associates, consultants,
subcontractors, or vendors. The term ENGINEER includes
ENGINEER's Consultants.
24. Field Order—A written order issued by ENGINEER
which directs minor changes in the Work but which does not
involve a change in the Contract Price or the Contract Times.
25. Final Completion shall mean that all work has been
completed, all final punch list items have been inspected and
satisfactorily completed, all payments to subcontractors have
been made, all documentation and warranties have been
submitted, all closeout documents have been executed and
approved by the OWNER, and the Project has been finally
accepted by the OWNER.
26. General Conditions -That part of the Contract
Documents which sets forth terms, conditions, and procedures
that govern the Work to be performed or furnished by
Contractor with respect to the Project.
27. Hazardous Environmental Condition—The presence
at the Site of Asbestos, PCB's, Petroleum, Hazardous Waste,
or Radioactive Materials in such quantities or circumstances
that may present a substantial danger to persons or property
exposed thereto in connection with the Work.
28. Hazardous Waste—The term Hazardous Waste shall
have the meaning provided in Section 1004 of the Solid Waste
Disposal Act (42 USC Section 6903) as amended from time to
time.
29. Laws and Regulations, Laws or Regulations—Any
and all applicable laws, rules, regulations, ordinances, codes,
standards, and orders of any and all governmental bodies,
agencies, authorities, and courts having jurisdiction.
30. PCB's—Polychlorinated biphenyls.
31. Petroleum—Petroleum, including crude oil or any
fraction thereof which is liquid at standard conditions of
temperature and pressure (60 degrees Fahrenheit and 14.7
pounds per square inch absolute), such as oil, petroleum, fuel
oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed
with other non -Hazardous Waste and crude oils.
32. Radioactive Materials—Source, special nuclear, or
byproduct material as defined by the Atomic Energy Act of
1954 (42 USC Section 2011 et seq.) as amended from time to
time.
33. Record Drawings—The Drawings as issued for
construction on which ENGINEER, upon completion of the
Work, has shown changes due to Addenda or Change Orders
and other information which ENGINEER considers
significant based on record documents furnished by
Contractor to ENGINEER and which were annotated by
Contractor to show changes made during construction.
34. Reimbursable Expenses—The expenses incurred
directly by ENGINEER in connection with the performing or
furnishing of Basic and Additional Services for the Project for
which OWNER shall pay ENGINEER as indicated in Exhibit
C.
35. Resident Project Representative—The authorized
representative of ENGINEER, if any, assigned to assist
ENGINEER at the Site during the Construction Phase. The
Resident Project Representative will be ENGINEER's agent
or employee and under ENGINEER's supervision. As used
herein, the term Resident Project Representative includes any
assistants of Resident Project Representative agreed to by
OWNER. The duties and responsibilities of the Resident
Project Representative are as set forth in Exhibit D.
36. Samples—Physical examples of materials, equipment,
or workmanship that are representative of some portion of the
Work and which establish the standards by which such portion
of the Work will be judged.
37. Shop Drawings—All drawings, diagrams,
illustrations, schedules, and other data or information which
are specifically prepared or assembled by or for Contractor
and submitted by Contractor to ENGINEER to illustrate some
portion of the Work.
38. Site—Lands or areas indicated in the Contract
Documents as being furnished by OWNER upon which the
Work is to be performed, rights-of-way and easements for
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 10 of 12
access thereto, and such other lands furnished by OWNER
which are designated for use of Contractor.
39. Specifications—That part of the Contract Documents
consisting of written technical descriptions of materials,
equipment, systems, standards, and workmanship as applied to
the Work and certain administrative details applicable thereto.
40. Substantial Completion—The time at which the Work
(or a specified part thereof) has progressed to the point where,
in the opinion of ENGINEER, the Work (or a specified part
thereof) is sufficiently complete, in accordance with the
Contract Documents, so that the Work (or a specified part
thereof) can be utilized for the purposes for which it is
intended. The terms "substantially complete" and
"substantially completed" as applied to all or part of the Work
refer to Substantial Completion thereof.
45. Written Amendment—A written amendment of the
Contract Documents signed by OWNER and Contractor on or
after the Effective Date of the Construction Agreement and
normally dealing with the non -engineering or non-technical
rather than strictly construction -related aspects of the Contract
Documents.
ARTICLE 8 - EXHIBITS AND SPECIAL
PROVISIONS
8.01 Exhibits Included
A. Exhibit A, "ENGINEER's Services," consisting of
fourteen (14) pages.
41. Supplementary Conditions—That part of the Contract B. Exhibit B, "OWNER's Responsibilities," consisting
Documents which amends or supplements the General of two (2) pages.
Conditions.
42. (Modified). Total Project Costs—The sum of the
Construction Cost, allowances for contingencies, the total
costs of services of ENGINEER or other design professionals
and consultants, cost of land, rights-of-way, compensation for
damages to properties, OWNER's costs for legal, accounting,
insurance counseling or auditing services, interest and
financing charges incurred in connection with the Project, and
the cost of other services to be provided by others to OWNER
pursuant to Exhibit B of this Agreement.
43. Work—The entire completed construction or the
various separately identifiable parts thereof required to be
provided under the Contract Documents with respect to this
Project. Work includes and is the result of performing or
furnishing labor, services, and documentation necessary to
produce such construction and furnishing, installing, and
incorporating all materials and all equipment into such
construction, all as required by the Contract Documents.
44. Work Change Directive—A written directive to
Contractor issued on or after the Effective Date of the
Construction Agreement and signed by OWNER upon
recommendation of ENGINEER, ordering an addition,
deletion, or revision in the Work, or responding to differing or
unforeseen subsurface or physical conditions under which the
Work is to be performed or to emergencies. A Work Change
Directive will not change the Contract Price or the Contract
Times but is evidence that the parties expect that the change
directed or documented by a Work Change Directive will be
incorporated in a subsequently issued Change Order following
negotiations by the parties as to its effect, if any, on the
Contract Price or Contract Times.
C. Exhibit C, "Payments to ENGINEER for Services
and Reimbursable Expenses," consisting of two (2) pages.
D. Exhibit D, "Duties, Responsibilities and Limitations
of Authority of Resident Project Representative," is not used.
E. Exhibit E, "Notice of Acceptability of Work," is
consisting of two (2) pages.
F. Exhibit F, "Construction Cost Limit," is not used.
G. Exhibit G, "Insurance," consisting of two (2) pages.
H. Exhibit H, "Dispute Resolution," is not used.
I. Exhibit I, "Allocation of Risks," is not used.
J. Exhibit J, "Special Provisions," is not used.
K. (Added). Exhibit K, "Indemnification," consisting of
two (2) pages.
8.02 Total Agreement
A. This Agreement (consisting of pages 1 to 12
inclusive, together with the Exhibits identified above)
constitutes the entire agreement between OWNER and
ENGINEER and supersedes all prior written or oral
understandings. This Agreement may only be amended,
supplemented, modified, or canceled by a duly executed
written instrument. This Agreement along with the exhibits
shall be read and construed as the same Agreement.
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 11 of 12
IN WITNESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is
indicated on page 1.
OWNER: CITY OF BAYTOWN ENGINEER: KIMI.EY-HORN AND ASSOCIATES,
INC.
Signature: Signature:
Printed Name: Richard L. Davis
Title: City Manager
Date Signed:
Address for giving notices:
P.O. Box 424
Baytown, Texas 77522
Designated Representative (paragraph 6.02.A):
Name: Ajay Shakyaver, P.E.
Title: Director of Engineering
Phone Number: (281)420-7154
Facsimile Number: (281) 420-6586
E -Mail Address: ai ay.shakyaver{a].bavtown.org
Printed Name:
Title:
Date Signed:
Address for giving notices:
11700 Katy Freeway, Suite 800
Houston, TX, 77079
Designated Representative (paragraph 6.02.A):
Name: Constance C. Curtis, P.E.
Title:
Phone Number: (281) 920-6578
Facsimile Number: (972)
E -Mail Address:
Standard Form of Agreement
Between Owner and Engineer for Professional Services
Page 12 of 12
This is EXMBIT A, consisting of 14 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Initial:
OWNER
ENGINEER
ENGINEER's Services
Article 1 of the Agreement is amended and supplemented to include the following agreement of the parties.
ENGINEER shall provide Basic and Additional Services as set forth below.
PART 1 — BASIC SERVICES (Modified).
A.1.005 Supporting Design Phase
A. ENGINEER shall:
1. Consult with OWNER to define and clarify OWNER's requirements for the Project and available data.
2. Advise OWNER as to the necessity of OWNER's providing data or services of the types described in
Exhibit B, which are not part of ENGINEER's Basic Services, and assist OWNER in obtaining such
data and services.
3. Attend meetings with OWNER to receive input into OWNER'S requirements for the Project and
evaluation of potential solutions available to OWNER and to discuss and finalize design criteria and
acquire pertinent information regarding the Project.
4. Perform or provide the following additional Supporting Design Phase tasks or deliverables:
TASK 1- Supporting Design Information for Goose Creek Lift Station Design (complete within 60
calendar days from Owner's issuance of notice to proceed)
This task includes the survey and geotechnical investigation at the Goose Creek Lift Station site. As
part of this task, ENGINEER will provide the following services:
a. EngineerCoordination—Survey
(1) Retain and coordinate with surveyor {subconsultant).
(2) Perform up to two (2) site visits to review topographic information provided by surveyor
for general compliance with the scope of services and observed field conditions.
(3) Review Digital Terrain Model and 1 -foot contours provided by surveyor for general
compliance with the scope of services and observed field conditions.
(4) Review electronic base files provided by surveyor in preparation for final lift station
design.
b. Topographic Surveyand Boundary Survey
(1) Perform or cause to be performed an ALTA/NSPS Land Title Survey
(a) Such survey shall include ALTA/NSPS 2016 Optional Table "A" items 1 ,2, 3, 4,
6b,7a,8, 9, 13, 14, 16, 17, 18, 19, & 20.
(b) Surveyor will review and show all existing encumbrances as reflected in current title
commitment provided by OWNER and is subject to the limitations and restrictions of
that commitment.
(c) All Horizontal Survey Control shall be referenced to the Texas State Plane
Coordinate System, South Central Zone, NAD83, and surveyor shall provide MY
Coordinates for all major property corners.
Page 1 of 14 Pages
(EXHIBIT A - Scope of Work)
(2) Perform or cause to be performed a Cat. 6,Cond. I Topographic, Utility Survey
(a) Topographic Survey will be performed on a 50' x 50' grid where available including
all visible grade breaks and changes in elevation. Topographic survey will show all
improvements within 20 feet of the property lines and will include all improvements,
elevations, observable utilities located within the subject property and within the
public right-of-way of Pecan Grove Dr., Pepper Mill St., and W. Cedar Bayou
Lynchburg Rd. at 50' x -sections within the subject area.
(b) Utility information shown on the survey is based on visible above ground
improvements and evidence found on-site at the time survey, coupled with markings
from Digtess, and available record drawings from the OWNER, Harris County,
TXDOT, applicable municipal utility district, Centerpoint Energy, Reliant Energy,
Southwestern Bell Telephone Company, and OWNER at the time of survey.
(c) Surveyor shall show that information which is marked and available at the time of
survey.
c. Engineer Coordination - Geotechnical Investigation
(1) Retain and coordinate with geotechnical engineer (subconsultant)
(2) Identify bore hole locations and submit exhibits to geotechnical engineer.
(3) Review geotechnical report and provide one (1) round of comments
d. Geotechnical Investigation
(1) Field Investigation: The proposed field investigation includes:
(a) One (1) boringtotaling 50 feet of drilling isincluded inthis scope ofwork.
(b) Field personnel will drill the borings using the equipment stated in our assumptions.
Cohesive and non -cohesive soil samples will be obtained usingthree-inch diameter Shelby
tube samplers (ASTM D-1587) and two-inch diameter standard split -spoon samplers
(ASTM D-1586), respectively.
(c) An engineering geologist or soils technicianwill extrude the samples inthefield, checkthe
samples for consistency with a hand penetrometer, carefully wrap them to preserve their
condition, and return them to the laboratory for testing. A log of boring will be prepared
to document field activities and results. GES will stake the boring location using normal
taping procedures. Location will be shown on the plano£boring.
(2) Laboratory Investigation - Laboratory tests will be required for classification purposes, to
determine strength characteristics, and to evaluate both the short- and long -tern
deformation/swell properties of the materials encountered. Testing will be in accordance with
standard procedures which include moisture content and soil identification, liquid and plastic
limit determinations, strength tests on soil, and unitweight determinations. The specific types
and quantities of tests will be determined based on soil conditions encountered in the
borings.
(3) Geotechnical Engineering Services - An addendum to report will be prepared by a
registered engineer with the subconstant and will present the results of the field and
laboratory data together with the subconsultant's analyses of the results and
recommendations. The subconsultant will provide a digitally signed and sealed report in
electronic PDF format. The report will address:
(a) Soil and groundwater conditions encountered at the boring locations;
(b) Lift station recommendations:
(c) Earthwork recommendations, including material and compaction requirements; and
(d) Construction considerations related to soil and groundwater conditions at the boring.
B. All services performed under this Supporting Design Phase shall be complete within sixty (60) calendar
days from the date of the notice to proceed.
A.1.01 Preliminary Design Phase
A. Upon written authorization from OWNER, ENGINEER shall:
1. Consult with OWNER to define and clarify OWNER's requirements for the Project and available data.
Page 2 of 14 Pages
(EXHIBIT A - Scope of Work)
2. Advise OWNER as to the necessity of OWNER's providing data or services of the types described in
Exhibit B, which are not part of ENGINEER's Basic Services, and assist OWNER in obtaining such
data and services.
3. Identify, consult with, and analyze requirements of OWNER, Union Pacific Railroad, the U.S. Army
Corps of Engineers, utility companies (phone, gas, electricity and cable), the Texas Department of
Transportation, and all other governmental authorities having jurisdiction to issue permit or to approve
the portions of the Project designed or specified by ENGINEER, including, but not limited to,
mitigating measures identified in the environmental assessment (if any).
4. Identify and evaluate potential solutions available to OWNER; and, after consultations with OWNER,
recommend to OWNER those solutions which in ENGINEER's judgment meet OWNER's
requirements for the Project.
5. Attend meetings with OWNER to receive input into OWNER'S requirements for the Project and
evaluation of potential solutions available to OWNER and to discuss and finalize design criteria and
acquire pertinent information regarding the Project.
6. (Modified) Perform or provide the following additional Preliminary Design Phase tasks or deliverables:
TASK 2 -Goose Creek Preliminary Engineering Report(PER) (complete within 90 calendar days
of OWNER's issuance of notice to proceed)
This task will include the Preliminary Engineering Report (PER), which will document the analysis of
the existing lift station capacity, projected ultimate flow, and rehabilitation options. As part of this task,
ENGINEER will provide the following services:
a. Goose Creek Lift Station Evaluation
(1) ENGINEER will utilize the Goose Creek Lift Station Analysis performed as part of the
San Jacinto Boulevard Roadway and Lift Station project to confirm the future projected
flow to the Goose Creek Lift Station.
(2) Once the future projected flow is confirmed by the OWNER, ENGINEER will compare
the existing capacity of the wet well and force main to the ultimate projected flow and
determine if the existing station is adequately sized per TCEQ requirements.
(3) ENGINEER will analyze two (2) options for rehabilitation of the lift station.
b. Goose Creek Force Main Analysis and Alignment Study
(1) ENGINEER will confirm the force main size for the re-routed section at Thompson/I H-
10.
(2) Transient Analysis - Utilizing the future projected flow conditions and the future projected
pump selection from the lift station analysis, through a sub -consultant, ENGINEER will
perform a transient analysis of the existing force main to determine the high and low
surges of the force main.
(3) Alignment Study - If the Transient Analysis results in needed improvement to the existing
20 -inch force main, ENGINEER will review the existing 20 -inch force main alignmentand
identify a preliminary proposed alignment for the proposed force main. This alignment
study will utilize available right-of-way and LIDAR information from the OWNER or
Harris County and will consist of an alignment on an aerial exhibit. The alignment study is
intended to identify potential conflicts along the alignment to allow ENGINEER to provide
preliminary probable construction costs.
c. Steinman Lift Station and Force Main Analysis
(1) ENGINEER will analyze the hydraulic conditions of the Steinman lift station and force
main based on existing pumping capacity and force main alignment.
(2) ENGINEER will calculate total dynamic head and flow based off the alignment change at
Thompson/IH-10 and document the following in a technical memorandum:
(a) Existingpumpingcapacity, force mainlength, velocity, flow, andtotal dynamic head.
(b) Changes in flow and total dynamic head based on the alignment change at
Page 3 of 14 Pages
(EXHIBIT A - Scope of Work)
Thompson/IH-10
(c) Recommendations for replacing pumps and pipe size for the proposed force main at
the Thompson/IH-10 development to meet TCEQ requirements.
(3) ENGINEER will provide a draft technical memorandum with the 90% Goose Creek Lift
Station PER.
(4) ENGINEER will provide one (1) hard copy and one (1) PDF copy of the technical
memorandum with the final Goose Creek Lift Station PER.
7. ENGINEER will prepare a preliminary Opinion of Probable Construction Cost (OPCC) for each
portion of the Project to be included with the tasks' respective memorandum.
8. Furnish three (3) review copies and one electronic pdf copy of the draft PER outlining the existing
condition of Goose Creek Lift Station, the transient analysis, the force main alignment study, proposed
recommendations at the lift station and along the force main alignment, and preliminary site plans
illustrating the proposed lift station recommendation to OWNER and review the PER with OWNER.
9. ENGINEER within ninety (90) calendar days of authorization to begin services will revise the PER
based upon comments received from the OWNER including OWNER's preferred option and furnish
two (2) final copies and one (1) electronic copy of the PER with the information contained in 7 and 8.
B. (Modified) ENGINEER's services under the Preliminary Design Phase will be considered complete on the
date when the final copies of the revised PER have been delivered to and accepted by OWNER.
A1.02 Final Design Phase
A. Upon written authorization from OWNER, ENGINEER shall:
1. (Modified) Prepare final Drawings indicating the scope, extent, and character of the Work to be performed
and furnished by Contractor. Specifications will be prepared, where appropriate, in conformance with the
16 -division format of the Construction Specifications Institute or other format agreed to in writing by
OWNER.
2. Provide technical criteria, written descriptions, and design data for OWNER's use in filing applications for
permits from or approvals of governmental authorities having jurisdiction to review or approve the final
design of the Project and assist OWNER in consultations with appropriate authorities.
3. Advise OWNER of any adjustments to the opinion of probable Construction Cost and any adjustments to
Total Project Costs known to ENGINEER.
4. (Modified) Attend meetings with, participate in conference calls with and prepare presentations for
OWNER and other applicable agencies, utility owners, pipelines, railroads, and other affected
stakeholders to review design details, to discuss and finalize design issues, and to coordinate the
Project.
5. Perform or provide the following additional final Design Phase tasks or deliverables:
Task 3A — Goose Creek Lift Station (This task entails everything in A1.02 with the exception of Task
4A) (Complete within 200 calendar days from the end of Task 2)
This task will provide for the final design of the Goose Creek Lift station, which will be designed so that
its electrical control panel, generator, and wet well roof will be elevated 2 -feet above the FEMA 500 -
year base flood elevation per Harris County requirements. As part of this task, ENGINEER will
provide the following services:
a. Preliminary and Final Platting
Through a subconsultant, ENGINEER shall prepare and submit a preliminary and final plat for
the two indicated properties shown on Appendix A-1 of Exhibit A.
Page 4 of 14 Pages
(EXHIBIT A - Scope of Work)
b. Lift Station Construction Plans
Final plans will consist of approximately twenty-five (25) - 22"x34" plan sheets. The anticipated
sheets in final design includes:
C.
d.
(1) Cover Page
(2) General Notes
(3) Site Civil Plans:
(a) Construction Sequencing/Bypass Pumping Plan
(b) Overall Dimensional Control Plan
(c) Lift Station Site Plan
(d) Lift Station Grading Plan
(e) Lift Station Details Pumps and Piping (Includes discharge piping)
(f) Construction Details
(g) Structural Lift Station Details (Sub -Consultant)
(h) Landscape Plans and Details
(i) Erosion Control Plans and Details
(4) Site Electrical (Sub -Consultant):
(a) General Sheets (legend, general notes)
(b) MCC Enclosure Plan and Elevation
(c) One -Line Diagram
(d) Pump Station Floor Plan and Details
(e) Generator Details
(f) Instrumentation Symbols and Legend
(g) Lift Station P&ID
(5) Site Structural (Sub -Consultant):
(a) Structural Notes
(b) Foundation and Upper Slab Plan
(c) Equipment Pads
(d) Sections and Details
(e) Typical Structural Details
Lift Station Project Manual and Technical Specifications:
(1) City of Baytown standard construction contract forms
(2) Notice to bidders
(3) Special instructions to bidders
(4) Bid form
(5) Standard construction contract
(6) Performance bond
(7) Payment bond
(8) Maintenance bond
(9) Certificate of insurance
(10) General conditions
(11) Special provisions
(12) Technical specifications
Deliverables:
(1) 90% Design Submittal shall include the following:
(a) Two (2) copies to the OWNER for review and comment of the following: 90% Final
design plans (full size).
➢ 90% Contract documents including technical specifications (EJCDC).
➢ 90% opinion of probable construction cost.
The ENGINEER will meet with the OWNER to review 90% submittal comments.
The ENGINEER will incorporate one round of 90% design review comments by the
OWNER.
(2) 100% Design Submittal for bidding shall include the following:
(a) Two (2) full-size sets of plans and specifications to the City;
(b) One (1) PDF set of plans and specifications to the City;
Page 5 of 14 Pages
(EXHIBIT A - Scope of Work)
(c) The final opinion of probable construction cost;
(d) A letter of notification to the City stating completion of the design of the project; and
(e) TCEQ compliance letter (submitted to TCEQ). A copy of the letter will be provided
to the OWNER.
B. (Modified) ENGINEER's services under the Final Design Phase will be considered complete on the date when
the submittals required by paragraph A1.02.A have been delivered to and accepted by OWNER and all
regulatory authorities have approved the same.
A1.03 Bidding or Negotiating Phase.
A. After acceptance by OWNER of the Bidding Documents and the most recent opinion of probable Construction
Cost as determined in the Final Design Phase and upon written authorization by OWNER to proceed with Task
3B or 4B, ENGINEER shall for the applicable task:
1. Assist OWNER in advertising for and obtaining bids for the Work.
2. Answer questions and issue Addenda as appropriate to clarify, correct, or change the Bidding Documents.
3. Consult with OWNER as to the acceptability of subcontractors, suppliers, and other individuals and
entities proposed by Contractor for those portions of the Work as to which such acceptability is required
by the Bidding Documents.
4. (Modified) Conduct the Pre -Bid Conference and prepare summary of pre-bid meeting minute for the
project and distribute to all prospective bidders.
5. (Modified) Attend the Bid opening, prepare Bid tabulation sheets, assemble contract documents, assist
OWNER in both evaluating Bids or proposals, recommend award to OWNER, as appropriate, and assist
in awarding contracts for the Work.
6. (Added) Assist in connection with Bid protests, rebidding, or re -negotiating contracts for construction,
materials, equipment, or services.
7. (Added) Provide the following bid phase services:
Task 3B for Goose Creek Lift Station (This task entails everything in this is A1.03 with the exception
of Task 4B)
a. Prepare a PDF of the Goose Creek Lift Station bid documents to be uploaded to the City's website to
be downloaded by prospective bidders; and
b. Prepare final construction documents, which shall include the following:
(1) Provide PDFs of the "Issued for Construction" Conformance Plans and Specifications to the
OWNER.
(2) Print two (2) full-size sets "Issued for Construction" Conformance Plans and Specifications to
Contractor upon award of contract.
(3) Print two (2) half-size sets "Issued for Construction" Conformance Plans for City's use.
(4) Furnishing additional copies of review documents and/or bid documents in excess of the
number of the same identified above will be considered as Additional Services.
B. (Modified) The Bidding or Negotiating Phase will be considered complete upon commencement of the
Construction Phase.
A1.04 Construction Phase
Page 6 of 14 Pages
(EXHIBIT A - Scope of Work)
A. Upon successful completion of the Bidding and Negotiating Phase, and upon written authorization from
OWNER, ENGINEER shall:
General Administration of Construction Contract. Consult with OWNER and act as OWNER's
representative as provided in the General Conditions. The extent and limitations of the duties,
responsibilities and authority of ENGINEER as assigned in said General Conditions shall not be
modified, except as ENGINEER may otherwise agree in writing. All of OWNER's instructions to
Contractor will be issued through ENGINEER, who shall have authority to act on behalf of OWNER
in dealings with Contractor to the extent provided in this Agreement and said General Conditions
except as otherwise provided in writing.
2. (Modified) Selecting Independent Testing Laboratory. Assist OWNER in the selection of an
independent testing laboratory to perform testing services, if any.
3. Pre -Construction Conference. Prepare a Pre -Construction Conference agenda and conduct a Pre -
Construction Conference prior to commencement of Work at the Site. Prepare and provide a summary
of the Pre -Construction Conference minutes for the project and distribute it to all parties
4. Baselines and Benchmarks. As appropriate, establish control and temporary benchmarks for locating
the Work which in ENGINEER's judgment are necessary to enable Contractor to proceed.
5. Visits to Site and Observation of Construction. In connection with observations of Contractor's work
in progress while it is in progress:
a. (Modified) Make visits to the Site at intervals appropriate to the various stages of construction,
and as ENGINEER and/or OWNER deems necessary, in order to observe as an experienced and
qualified design professional the progress and quality of the Work. Such visits and observations
by ENGINEER, and the Resident Project Representative, if any, are not intended to be
exhaustive or to extend to every aspect of Contractor's work in progress or to involve detailed
inspections of Contractor's work in progress beyond the responsibilities specifically assigned to
ENGINEER in this Agreement and the Contract Documents, but rather are to be limited to spot
checking, selective sampling, and similar methods of general observation of the Work based on
ENGINEER's exercise of professional judgment as assisted by the Resident Project
Representative, if any. Based on information obtained during such visits and such observations,
ENGINEER will determine if Contractor's work is proceeding in accordance with the Contract
Documents, and ENGINEER shall keep OWNER informed of the progress of the Work.
b. (Modified) The purpose of ENGINEER's visits to, and representation by the Resident Project
Representative, if any, at the Site, will be to enable ENGINEER to better carry out the duties and
responsibilities assigned to and undertaken by ENGINEER during the Construction Phase, and,
in addition, by the exercise of ENGINEER's efforts as an experienced and qualified design
professional, to provide for OWNER a greater degree of confidence that the completed Work
will substantially conform to the Contract Documents and that the integrity of the design concept
of the completed Project as a functioning whole as indicated in the Contract Documents has been
implemented and preserved by Contractor. ENGINEER shall not, during such visits or as a
result of such observations of Contractor's work in progress, supervise, direct, or have control
over Contractor's work, nor shall ENGINEER have authority over or responsibility for the
means, methods, techniques, sequences, or procedures of construction selected by Contractor, for
safety precautions and programs incident to Contractor's work, or for any failure of Contractor to
comply with Laws and Regulations applicable to Contractor's furnishing and performing the
Work. Accordingly, ENGINEER neither guarantees the performance of any Contractor nor
assumes responsibility for any Contractor's failure to furnish and perform its work in accordance
with the Contract Documents.
Page 7 of 14 Pages
(EXHIBIT A - Scope of Work)
6. (Modified) Defective Work. Recommend to OWNER that Contractor's work be disapproved and
rejected while it is in progress if, on the basis of such observations, ENGINEER believes that such
work will not produce a completed Project that substantially conforms to the Contract Documents or
that it will prejudice the integrity of the design concept of the completed Project as a functioning
whole as indicated in the Contract Documents.
7. Clarifications and Interpretations; Field Orders. Issue necessary clarifications and interpretations of
the Contract Documents as appropriate to the orderly completion of Contractor's work. Such
clarifications and interpretations will be consistent with the intent of and reasonably inferable from the
Contract Documents. ENGINEER may issue Field Orders authorizing minor variations from the
requirements of the Contract Documents.
8. Change Orders and Work Change Directives. Recommend Change Orders and Work Change
Directives to OWNER, as appropriate, and prepare Change Orders and Work Change Directives as
required.
9. Shop Drawings and Samples. Review and approve or take other appropriate action in respect to Shop
Drawings and Samples and other data which Contractor is required to submit, but only for
conformance with the information given in the Contract Documents and compatibility with the design
concept of the completed Project as a functioning whole as indicated in the Contract Documents.
Such reviews and approvals or other action will not extend to means, methods, techniques, sequences
or procedures of construction or to safety precautions and programs incident thereto. ENGINEER
has an obligation to meet any Contractor's submittal schedule that has earlier been acceptable to
ENGINEER.
10. Substitutes and "or -equal. " Evaluate and determine the acceptability of substitute or "or -equal"
materials and equipment proposed by Contractor, but subject to the provisions of paragraph A2.01 of
this Exhibit A.
11. Inspections and Tests. Require such special inspections or tests of Contractor's work as deemed
reasonably necessary, and receive and review all certificates of inspections, tests, and approvals
required by Laws and Regulations or the Contract Documents. ENGINEER's review of such
certificates will be for the purpose of determining that the results certified indicate compliance with
the Contract Documents and will not constitute an independent evaluation that the content or
procedures of such inspections, tests, or approvals comply with the requirements of the Contract
Documents. ENGINEER shall be entitled to rely on the results of such tests.
12. Perform or provide the following additional Construction Phase tasks or deliverables:
Task 3C. — Record Drawings for Goose Creek Lift Station (This task entails everything in
this is A1.04 with the exception of Task 4C)
Provide the following deliverables:
➢ One (1) set of reproducible (22" x 34") Record Drawings;
➢ One (1) set of reproducible (11" x 17") Record Drawings; and
➢ One (1) PDF file Record Drawings {all sheets will be compiled into one PDF).
13. (Modified) Disagreements between OWNER and Contractor. Render formal written decisions on all
claims of OWNER and Contractor relating to the acceptability of Contractor's work or the
interpretation of the requirements of the Contract Documents pertaining to the execution and progress
of Contractor's work. In rendering such decisions, ENGINEER shall be fair and not show partiality
to OWNER or Contractor.
Page 8 of 14 Pages
(EXHIBIT A - Scope of Work)
14. Applications for Payment. Based on ENGINEER's observations as an experienced and qualified
design professional and on review of Applications for Payment and accompanying supporting
documentation:
a. Determine the amounts that ENGINEER recommends Contractor be paid. Such
recommendations of payment will be in writing and will constitute ENGINEER's representation
to OWNER, based on such observations and review, that, to the best of ENGINEER's
knowledge, information and belief, Contractor's work has progressed to the point indicated, the
quality of such work is substantially in accordance with the Contract Documents (subject to an
evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the
results of any subsequent tests called for in the Contract Documents and to any other
qualifications stated in the recommendation), and the conditions precedent to Contractor's being
entitled to such payment appear to have been fulfilled in so far as it is ENGINEER's
responsibility to observe Contractor's work. In the case of unit price work, ENGINEER's
recommendations of payment will include final determinations of quantities and classifications of
Contractor's work (subject to any subsequent adjustments allowed by the Contract Documents).
The responsibilities of ENGINEER contained in paragraph A1.04.A.5.a are expressly subject to
the limitations set forth in paragraph A1.04.A.5.b and other express or general limitations in this
Agreement and elsewhere.
b. By recommending any payment, ENGINEER shall not thereby be deemed to have represented
that observations made by ENGINEER to check the quality or quantity of Contractor's work as it
is performed and furnished have been exhaustive, extended to every aspect of Contractor's work
in progress, or involved detailed inspections of the Work beyond the responsibilities specifically
assigned to ENGINEER in this Agreement and the Contract Documents. Neither ENGINEER's
review of Contractor's work for the purposes of recommending payments nor ENGINEER's
recommendation of any payment including final payment will impose on ENGINEER
responsibility to supervise, direct, or control Contractor's work in progress or for the means,
methods, techniques, sequences, or procedures of construction or safety precautions or programs
incident thereto, or Contractor's compliance with Laws and Regulations applicable to
Contractor's furnishing and performing the Work. It will also not impose responsibility on
ENGINEER to make any examination to ascertain how or for what purposes Contractor has used
the moneys paid on account of the Contract Price, or to determine that title to any portion of the
work in progress, materials, or equipment has passed to OWNER free and clear of any liens,
claims, security interests, or encumbrances, or that there may not be other matters at issue
between OWNER and Contractor that might affect the amount that should be paid.
15. Contractor's Completion Documents.
a. (Modified) Receive and review maintenance and operating instructions, schedules, and
guarantees as prepared by the Contractor in accordance with the Contract Documents.
ENGINEER will compile this information as provided by Contractor, and deliver three (3)
copies of the same to OWNER.
b. (Modified) Receive bonds, certificates, or other evidence of insurance not previously
submitted and required by the Contract Documents, certificates of inspection, tests and
approvals, Shop Drawings, Samples and other data approved as provided under paragraph
A1.04.A.9, and the annotated record documents which are to be assembled by Contractor in
accordance with the Contract Documents to obtain final payment. The extent of such
ENGINEER's review will be limited as provided in paragraph A1.04.A.9.
c. ENGINEER shall transmit these documents to OWNER within thirty days of receipt of
documents from Contractor.
Page 9 of 14 Pages
(EXHIBIT A - Scope of Work)
d. (Added) Preparing and furnishing to OWNER Record Drawings electronically in a format
approved by the OWNER and on mylar showing appropriate record information based on Project
annotated record documents received from Contractor.
16. (Modified) Final Notice of Acceptability of the Work. Conduct a final inspection to determine if the
completed Work of Contractor is acceptable so that ENGINEER may recommend, in writing, final
payment to Contractor. Accompanying the recommendation for final payment, ENGINEER shall
also provide a notice in the form attached hereto as Exhibit E (the "Notice of Acceptability of Work")
that to the best of ENGINEER's knowledge, information and belief and upon the exercise of
ENGINEER'S due diligence, the Work is acceptable and is in compliance with the Contract
Documents.
B. Duration of Construction Phase. The Construction Phase will commence with the execution of the first
Construction Agreement for the Project or any part thereof and will terminate upon final payment to
Contractors.
C. Limitation of Responsibilities. ENGINEER shall not be responsible for the acts or omissions of any
Contractor, or of any of its subcontractors, suppliers, or of any other individual or entity performing or
furnishing any of the Work. ENGINEER shall not be responsible for failure of any Contractor to perform or
furnish the Work in accordance with the Contract Documents.
PART 2 — ADDITIONAL SERVICES
A2.01 Additional Services Requiring OWNER's Authorization in Advance.
A. Should OWNER desire to add the replacement of 11,700 linear feet of 20 -inch Force Main,
1. The following shall be included as part of the Final Design Phase Services:
Task 4A — Goose Creek Force Main (This task entails everything in A1.02 with the exception of Task
3A) (Complete within 175 Calendar Days)
This task will provide for the final design of the Goose Creek Force Main. As part of this task,
ENGINEER will provide the following services:
a. Additional Topographic Survey
Through a subconsultant, additional topographic survey required for the force main design
will be obtained at the locations indicated in Appendix A-2 of Exhibit A.
ENGINEER will provide the following services for survey coordination:
(1) Coordinate with surveyor (subconsultant).
(2) Perform site visits to review topographic information provided by surveyor for general
compliance with the scope of services and observed field conditions.
(3) Review Digital Terrain Model and 1 -foot contours provided by surveyor for
general compliance with the scope of services and observed field conditions.
(4) Review electronic base files provided by surveyor in preparation for final lift station
design.
ENGINEER's subconsultant will provide the following services for this task:
(1) Cat. 6, Cond. I Topographic, Utility Survey
(a) Topographic Survey will be performed on a 50' x 50' grid where available
including all visible grade breaks and changes in elevation. Topographic survey
will show all improvements within 20 feet of the property lines and will include
all improvements, elevations, observable utilities located within the subject
property and within portions of W. Cedar Bayou Lynchburg Rd. and Thompson
Rd. at 50' x -sections within the subject area. Includes eastern boundary of
Page 10 of 14 Pages
(EXHORT A - Scope of Work)
WWTP.
(b) Utility information shown on the survey is based on visible above ground
improvements and evidence found on-site at the time survey, coupled with
markings from Digtess, and available record drawings from the City of Baytown,
Harris County, TXDOT, Applicable M.U.D., Centerpoint Energy, Reliant Energy,
Southwestern Bell Telephone Company, and Client at the time of survey.
(c) Surveyor shall show that information which is marked and available at the time of
survey. Surveyor is not responsible for other utility lines or plans that may exist or
discovered during future investigation or uncovered during ongoing construction
phases.
b. Additional Geotechnical Investigation
Through a subconsultant, additional geotechnical investigation required for the force main
design will be obtained.
ENGINEER will provide the following services for survey coordination:
(1) Coordinate with geotechnical engineer (subconsultant)
(2) Review geotechnical report and provide one (1) round of comments
ENGINEER's subconsultant will provide the following services for this task:
(1) Geotechnical Investigation
(a) Field Investigation: The proposed field investigation includes:
1. Twenty-six (26) borings totaling 90 feet of drilling is included in this scope of
work.
2. Field personnel will drill the borings using the equipment stated in our
assumptions. Cohesive and non -cohesive soil samples will be obtained using
three-inch diameter Shelby tube samplers (ASTM D-1587) and two-inch
diameter standard split -spoon samplers (ASTM D-1586), respectively.
3. An engineering geologist or soils technician will extrude the samples in the
field, check the samples for consistency with a hand penetrometer, carefully
wrap them to preserve their condition, and return them to the laboratory for
testing. A log of boring will be prepared to document field activities and results.
GES will stake the boring location using normal taping procedures. Location
will be shown on the plan of boring. Precise surveying of boring location and
elevation is not included in the cost estimate. These services may be provided
upon request, at additional cost. At the completion of drilling operations, bore
holewill be backfilled andpluggedwith soil cuttings.
(2) Laboratory Investigation - Laboratory tests will be required for classification purposes,
to determine strength characteristics, and to evaluate both the short- and long-term
deformation/swell properties of the materials encountered. Testing will include moisture
content and soil identification, liquid and plastic limit determinations, strength tests on
soil, and unit weight determinations. The specific types and quantities of tests will be
determined based on soil conditions encountered in the borings.
(3) Geotechnical Engineering Services - Report will be prepared by a registered engineer
with the sub -constant and will present the results of the field and laboratory data
together with the sub -consultant's analyses of the results and recommendations. The sub -
consultant will provide a digitally signed and sealed report in electronic PDF format.
The report will address:
(a) Soil and groundwater conditions encountered at the boring locations; Trench safety
recommendations;
(b) Earthwork recommendations, including material and compaction requirements; and
(c) Construction considerations related to soil and groundwater conditions at the
boring.
c. Goose Creek Force Main Subsurface Utility Engineering (SUE)
Through a sub -consultant, SUE along the force main alignment will be obtained at the
locations shown in Appendix A-2 of Exhibit A.
Page 11 of 14 Pages
(EXHIBIT A - Scope of Work)
ENGINEER's sub -consultant will provide the following services for this task:
(1) Quality Level "A" (QL-A) — three dimensional (x,yz) utility information obtained utilizing
non-destructive vacuum excavation equipment to expose utilities at critical points which
are then tied down by surveying. Also known as "locating", this quality level provides
precise horizontal and vertical positioning of utilities within approximately 0.05 feet.
(2) In general, the scope of work involves performing QL-A SUE on thirteen (13) pipelines
that cross the alignment of the Goose Creek force main along W. Cedar Bayou Lynchburg
and Thompson Road.
(3) Provide a field sketch depicting the approximate horizontal position of the designated
pipelines.
(4) Provide a summary sheet containing test hole field notes.
(5) Provide survey for the test hole locations.
d. Force Main Construction Plans
The force main plans will consist of approximately forty (40) — 22"04" sheets. The anticipated
sheets infinal design includes:
(1) Cover Page
(2) General Notes
(3) Overall Utility Sheet
(4) Bypass Pumping Plan
(5) Force main plan/profile (approximately thirty (3 0) sheets)
(6) Construction Details including City of Baytown Standard details
(7) Traffic Control Plan and Details
e. Force Main Project Manual and Technical Specifications:
(1) City of Baytown standard construction contract forms
(2) Notice to bidders
(3) Special instructions to bidders
(4) Bid form
(5) Standard construction contract
(6) Performance bond
(7) Payment bond
(8) Maintenance bond
(9) Certificate of insurance
(10)General conditions
(11) Special provisions
(12)Technical specifications
L Permitting and Agency Coordination:
(1) ENGINEER will identify franchise utility or gas line company contacts and send one set
of plans to each franchise utility or gas line company for their review.
(2) ENGINEER will request each franchise utility or gas line company to mark up the plans
to show the size, type, and location of their utilities. ENGINEER will prepare required
submittals and address comments from the franchise utility or gas line company to
attempt to gain Letters of No Objection {LONO's) from the franchise utility or gas line
company.
(3) ENGINEER will notify the City if any pipeline relocations are required.
(4) ENGINEER will coordinate and submit railroad pipeline crossing application.
ENGINEER will prepare required submittals and address comments from the railroad to
attempt to gain the railroad's approval of the pipeline crossing.
(5) ENGINEER will coordinate with the San Jacinto River Authority (SJRA) regarding the
crossing requirements for the SJRA South Canal. ENGINEER will prepare required
submittals and address comments from the SJRA to attempt to gain the SJRA's approval
of the pipeline crossing.
(6) ENGINEER will coordinate with the Hams County Flood Control District {HCFCD)
regarding the crossing requirements for Goose Creek. ENGINEER will prepare required
Page 12 of 14 Pages
(EXHIBIT A - Scope of Work)
submittals and address comments from the HCFCD to attempt to gain the HCFCD's
approval of the pipeline crossing.
(7) ENGINEER will submit one set of final design plans and the project schedule to each
affected franchise utility or gas line companies, the SJRA, and HCFCD for their review
and comment
(8) OWNER shall perform the coordination with the franchise utilities if any relocations are
required
g. Deliverables:
(1) 90% Design Submittal shall include the following:
(a) Submit two (2) copies to the OWNER for review and comment of the following:
(b) 90% Final design plans (full size)
(c) 90% Contract documents including technical specifications
(d) 90% opinion of probable construction cost
(2) ENGINEER will meet with the OWNER once to review 90% submittal comments.
ENGINEER will incorporate one round of 90% design review comments by OWNER
(3) 100% Design Submittal for bidding shall include the following:
(a) Submit two (2) full-size sets of plans and specifications to the City ii. Submit one
{1) PDF set of plans and specifications to the City
(b) Submit the final opinion of probable construction cost
(c) Submit a letter of notification to the City stating completion of the design of the
project
(d) TCEQ compliance letter (submitted to TCEQ). A copy of the letter will be provided
to the OWNER.
2. The following shall be included as part of the Bid Phase Services:
Task 4B for Goose Creek Force Main (This task entails everything in A1.03 with the exception of
Task 3B)
a. Prepare a PDF of the Goose Creek Force Main bid documents to be uploaded to the City's website to
be downloaded by prospective bidders; and
b. Prepare final construction documents, which shall include the following:
(1) Provide PDF's of the "Issued for Construction" Conformance Plans and Specifications to the
OWNER
(2) Print two (2) full-size sets "Issued for Construction" Conformance Plans and Specifications to
Contractor upon award of contract.
(3) Print two (2) half-size sets "Issued for Construction" Conformance Plans for City's use.
(4) Furnishing additional copies of review documents and/or bid documents in excess of the
number of the same identified above will be considered as Additional Services.
3. The following shall be included as part of the Construction Phase Services:
Task 4C — Record Drawings for Goose Creek Force Main (This task entails everything in A1.04
with the exception of Task 3C)
Provide the following deliverables:
➢ One (1) set of reproducible (22" x 34") Record Drawings;
➢ One (1) set of reproducible (11" x 17") Record Drawings; and
➢ One (1) PDF file Record Drawings (all sheets will be compiled into one PDF).
4. The following shall be the costs of the Additional Services detailed in A2.01.A:
Page 13 of 14 Pages
(EXHIBIT A - Scope of Work)
Task Phase
Creek Force Main
Amount
Not to
Exceed
4B Bidding Phase — Goose Creek
Force Main
$10,000.00
4C Construction Phase -- Goose
Creek Force Main
$40,000.00
Reimbursable Expenses
$5,000.00
Total NTE
$433.000.00
A2.02 Required Additional Services.
Not Included.
Page 14 of 14 Pages
(EXHIBIT A - Scope of Work)
This is EXHIBIT B, consisting of 2 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Initial:
OWNER
ENGINEER
OWNER's Responsibilities
Article 2 of the Agreement is amended and supplemented to include the following agreement of the parties.
B2.01 In addition to other responsibilities of OWNER as set forth in this Agreement, OWNER shall:
A. Provide ENGINEER with all criteria and full information as to OWNER's requirements for the Project,
including design objectives and constraints, space, capacity and performance requirements, flexibility, and
expandability, and any budgetary limitations; and fiunish copies of all design and construction standards which OWNER
will require to be included in the Drawings and Specifications; and furnish copies of OWNER's standard forms,
conditions, and related documents for ENGINEER to include in the Bidding Documents, when applicable.
B. Furnish to ENGINEER any other available information pertinent to the Project including reports and data
relative to previous designs, or investigation at or adjacent to the Site. Nothing contained in this Exhibit or in this
Agreement shall be construed to require the OWNER to provide such records in any certain format. The format in
which the existing data and documentation will be provided shall be at the sole discretion of the OWNER.
C. (Modified). Following ENGINEER's assessment of initially -available Project information and data and upon
ENGINEER's written request, furnish or otherwise make available such additional available Project related information
and data as is reasonably required to enable ENGINEER to complete its Basic and Additional Services.
1. (Deleted).
2. (Deleted).
3. (Deleted).
4. (Deleted).
5. (Deleted).
6. (Deleted).
D. (Deleted).
E. (Modified). Authorize ENGINEER to provide Additional Services as set forth in Part 2 of Exhibit A of the
Agreement as the OWNER determines is necessary.
F. (Modified). Arrange for access to and make all provisions for ENGINEER to enter upon public and private
property as required for ENGINEER to perform services under the Agreement.
G. Examine all alternate solutions, studies, reports, sketches, Drawings, Specifications, proposals, and other
documents presented by ENGINEER (including obtaining advice of an attorney, insurance counselor, and other advisors
or consultants as OWNER deems appropriate with respect to such examination) and render in writing timely decisions
pertaining thereto.
Page 1 of 2 Pages
(Exhibit B — OWNER's Responsibilities)
H. (Deleted).
I. (Deleted).
J. Advise ENGINEER of the identity and scope of services of any independent consultants employed by
OWNER to perform or famish services in regard to the Project, including, but not limited to, cost estimating, project
peer review, value engineering, and constructability review.
K. (Deleted).
L. (Deleted).
M. (Deleted).
N. (Deleted).
Page 2 of 2 Pages
(Exhibit B — OWNER's Responsibilities)
This is EXHIBIT C, consisting of 2 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Payments to ENGINEER for Services and Reimbursable Expenses
Article 4 of the Agreement is amended and
supplemented to include the following agreement of
the parties:
ARTICLE 4 -- PAYMENTS TO ENGINEER
C4.01 For Basic Services Having A Determined
Scope —Cost not to Exceed Method of
Payment
A. OWNER shall pay ENGINEER for Basic
Services set forth in Exhibit A as follows:
1. (Modified). A cost not to exceed
amount of $460,000.00, based upon the rate
schedule, which is attached as Appendix 1 of
Exhibit C and incorporated herein for all intents
and purposes. This amount includes those
ENGINEER'S Consultant's charges and will be
distributed at the completion of each phase in the
following amount:
Task
1
1111ase
Supporting Design Information
Amount
Not to
Exceed
$15,000.00
Phase
2
Goose Creek Preliminary
$95,000.00
Engineering Phase
3A
Final Design Phase — Goose
$250,000.00
Creek Lift Station
3B
Bidding Phase — Goose Creek
$15,000.00
Lift Station
3C
Construction Phase — Goose
$85,000.00
Creek Lift Station
Total NTE
$460.000.00
2. (Deleted).
3. The cost not to exceed includes
compensation for ENGINEER's services and
services of ENGINEER's Consultants.
Appropriate amounts have been incorporated in
the cost not to exceed to account for labor,
overhead, and profit.
Initial:
OWNER
ENGINEER
4. The portion of the amount billed for
ENGINEER's services will be based upon total
services actually completed during the billing
period, which shall be a calendar month. Invoices
shall be tendered no more often than once a month
for all of the services performed during the
applicable month.
C4.02 For Basic Services Having An Undetermined
Scope — Direct Labor Costs Imes a Factor
Method of Payment
A. (Not Used).
C4.03 For Additional Services
A. OWNER shall pay ENGINEER for
Additional Services as follows:
1. General. For services of ENGINEER's
employees engaged directly on the Project
pursuant to paragraph A2.01 or A2.02 of Exhibit
A of the Agreement, an amount based upon the
actual hours worked and the rate schedule, which
is attached as Appendix 1 of Exhibit C and
incorporated herein for all intents and purposes
plus Reimbursable Expenses. Additional Services
shall not be performed without the prior written
consent of the OWNER.
C4.04 For Reimbursable Expenses
A. (Modified). When not included in
compensation for Basic Services under paragraph
C4.01, OWNER shall pay ENGINEER for
Reimbursable Expenses as the rate set forth in
Appendix 2 of this Exhibit C. Before the OWNER
shall be liable for any reimbursable expenses,
ENGINEER must obtain prior written approval of the
OWNER of any expense that exceeds $1,000 for
which ENGINEER seeks reimbursement.
Reimbursable Expenses shall not exceed $5,000.00
(which include the Factor) whether incurred by
ENGINEER or ENGINEER's consultant(s).
B. (Modified). Reimbursable Expenses include
the following categories: mileage, parking tolls, long
Page 1 of 2 Pages
(Exhibit C - Basic Services With Determined Scope -- Cost not to exceed Method)
distance, reproduction of Drawings, Specifications,
Bidding Documents, and similar Project -related items
in addition to those required under Exhibit A, and, if
authorized in advance by OWNER.
C. The amounts payable to ENGINEER for
Reimbursable Expenses will be the Project -related
internal expenses actually incurred or allocated by
ENGINEER, plus all invoiced external Reimbursable
Expenses allocable to the Project, the latter multiplied
by a Factor of 1.10. Travel, meals, mileage, rental
cars, and like expenses are not subject to the 1.10
Factor.
D. (Deleted).
E. (Added). The OWNER must approve all
travel expenses before the same are incurred. If such
approval is not obtained, the OWNER shall not be
liable for such travel expenses.
C4.05 (Deleted).
Page 2 of 2 Pages
(Exhibit C - All Other Services/Charges -- Cost not to Exceed Method of Payment)
APPENDIX 1 OF EXHIBIT C — HOURLY RATES
Hourly Rates:
All services are to be billed on an hourly basis based on time and materials and based upon the following rates:
POSITION
Analyst
110URLI"
$ 105-$175
Professional
$160-$210
Senior Professional I
$180-$250
Senior Professional H
$240-$265
Support Staff
$75-$115
Senior Technical Support
$115-$190
Technical Support
$70-$100
Page 1 of 1 Pages
(Appendix 1 of Exhibit C — Hourly Rates)
APPENDIX 2 OF EDIT C — REIMBURSEMENT OF COSTS
External Reproduction and Deliveries: Cost plus 10%
Internal expenses: Cost
Mileage: IRS Rate
Travel: Cost
Page 1 of 1 Pages
(Appendix 2 of Exhibit C — Reimbursement of Costs)
This is EXHIBIT E, consisting of 2 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
NOTICE OF ACCEPTABILITY OF WORK
PROJECT:
OWNER:
OWNER'S Construction Contract Identification:
EFFECTIVE DATE OF THE CONSTRUCTION AGREEMENT:
CONSTRUCTION CONTRACT DATE:
ENGINEER:
To:
And To:
CONTRACTOR
Initial:
OWNER
ENGINEER
The undersigned hereby gives notice to the above OWNER and CONTRACTOR that the completed Work
furnished and performed by CONTRACTOR under the above Contract is acceptable, expressly subject to the
provisions of the related Contract Documents and the terms and conditions set forth on the reverse side hereof.
By:
Dated:
Page 1 of 2 Pages
(Exhibit E — Notice of Acceptability of Work)
(Reverse side of Notice)
CONDITIONS OF NOTICE OF ACCEPTABILITY OF WORK
The Notice of Acceptability of Work ("Notice") on the front side of this sheet is expressly made subject to the
following terms and conditions to which all persons who receive said Notice and rely thereon agree:
1. Said Notice is given with the skill and care ordinarily used by members of ENGINEERing profession practicing
under similar conditions at the same time and in the same locality.
2. Said Notice reflects and is an expression of the professional judgment of ENGINEER.
3. Said Notice is given as to the best of ENGINEER's knowledge, information, and belief as of the date hereof.
4. (Modified). Said Notice is based entirely on and expressly limited by the scope of services ENGINEER has
been employed by OWNER to perform or furnish during construction of the Project (including observation of
the CONTRACTOR's work) under ENGINEER's Agreement with OWNER and applies to facts that are within
ENGINEER's knowledge or could or should have been ascertained by ENGINEER as a result of carrying out
the responsibilities specifically assigned to ENGINEER under ENGINEER's agreement with OWNER.
5. (Modified). Said Notice is not a guarantee or warranty of CONTRACTOR'S performance under the
Construction Contract nor an assumption of responsibility for any failure of the Contractor to furnish and
perform the work thereunder in accordance with the Contract documents, unless ENGINEER knew or should
have known of such failure and failed to notify the Owner of such failure and take appropriate action so that the
same were corrected and brought into compliance with the Contract Documents.
Page 2 of 2 Pages
(Exhibit E — Notice of Acceptability of Work)
This is EXHIBIT G, consisting of 2 pages, referred to in and
part of the Agreement between OWNER and ENGINEER
for Professional Services dated
Initial:
OWNER
ENGINEER
Insurance
Paragraph 6.05 of the Agreement is amended and supplemented to include the following agreement of the parties.
G6.05 Insurance
Throughout the term of this Agreement, ENGINEER at its own expense shall purchase, maintain and keep in force
and effect insurance against claims for injuries to or death of persons or damages to property which may arise out of
or result from ENGINEER's operations and/or performance of the work under this Agreement, whether such
operations and/or performance be by ENGINEER, its agents, representatives, volunteers, employees or
subcontractors or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them
may be liable.
ENGINEER's insurance coverage shall be primary insurance with respect to the OWNER, its officers, agents and
employees. Any insurance or self-insurance maintained by the OWNER, its officials, agents and employees shall be
considered in excess of ENGINEER's insurance and shall not contribute to it. Further, ENGINEER shall include all
subcontractors as additional insureds under its commercial general liability policies or shall furnish separate
certificates and endorsements for each subcontractor. All coverage for subcontractors shall be subject to all of the
requirements stated herein.
The following is a list of standard insurance policies along with their respective minimum coverage amounts required
in this contract:
Commercial General Liability (CGL)
General Aggregate: $2,000,000
Products & Completed Operations: $1,000,000
Personal & Advertising Injury: $1,000,000
Per Occurrence: $1,000,000
a. Coverage shall be broad form CGL.
b. No coverage shall be excluded from standard policy without notification of individual exclusions being
attached for review and acceptance.
Business Automobile Policy (BAP)
Combined Single Limits: $1,000,000
a. Coverage for "Any Auto."
Workers' Compensation Insurance
Statutory Limits
Employer's Liability $1,000,000
Waiver of Subrogation required
Errors & Omissions (E&O)
Limit: $2,000,000
a. For all engineers, and/or design companies.
b. Claims -made form is acceptable.
c. Coverage will be in force for three (3) years after project is completed.
Page 1 of 2 Pages
(Exhibit G - Insurance)
Upon execution of this contract, ENGINEER shall file with the OWNER valid Certificates of Insurance and
endorsements acceptable to the OWNER. Such Certificates shall contain a provision that coverage afforded under
the policies will not be canceled, suspended, voided, or reduced until at least thirty (30) days' prior written notice has
been given to the OWNER via certified mail, return receipt requested.
ENGINEER shall also file with the OWNER valid Certificates of Insurance covering all subcontractors.
The following are general requirements applicable to all policies:
a. AM Best Rating of A -:VII or better.
b. Waiver of subrogation required.
c. Insurance carriers licensed and admitted to do business in State of Texas will be accepted.
d. Liability policies will be on occurrence form. E & O can be on claims -made form.
e. OWNER, its officers, agents and employees are to be added as Additional Insured to the commercial general
liability and business automobile policies.
f. Upon request of and without cost to OWNER, certified copies of all insurance policies and/or certificates of
insurance shall be furnished to OWNER's representative. Certificates of insurance showing evidence of
insurance coverage shall be provided to OWNER's representative prior to execution of this agreement.
g. Upon request of and without cost to OWNER, loss runs (claims listing) of any and/or all insurance coverage
shall be furnished to OWNER's representative.
Page 2 of 2 Pages
(Exhibit G - Insurance)
This is EDIT K, consisting of 2 pages, referred to in and part of
the Agreement between OWNER and ENGINEER for
Professional Services dated
Initial:
OWNER
ENGINEER
Indemnification
ENGINEER AGREES TO AND SHALL INDEMNIFY AND HOLD HARMLESS
AND DEFEND OWNER, ITS OFFICERS, AGENTS, AND EMPLOYEES
(HEREAFTER REFERRED TO AS "OWNER") FROM AND AGAINST ANY AND
ALL CLAIMS, LOSSES, DAMAGES, CAUSES OF ACTION, SUITS AND
LIABILITY OF EVERY HIND, INCLUDING ALL EXPENSES OF LITIGATION,
COURT COSTS, AND ATTORNEY'S FEES, FOR INJURY TO OR DEATH OF
ANY PERSON, FOR DAMAGE TO ANY PROPERTY OR FOR ANY BREACH OF
CONTRACT TO THE EXTENT ARISING OUT OF OR IN CONNECTION WITH
AN ACT OF NEGLIGENCE, INTENTIONAL TORT, INTELLECTUAL
PROPERTY INFRINGEMENT, OR FAILURE TO PAY A SUBCONTRACTOR OR
SUPPLIER COMMITTED BY ENGINEER OR ENGINEER'S AGENT, ENGINEER
UNDER CONTRACT, OR ANOTHER ENTITY OVER WHICH ENGINEER
EXERCISES CONTROL (COLLECTIVELY ENGINEER'S PARTIES). IT IS THE
EXPRESSED INTENTION OF THE PARTIES HERETO, BOTH ENGINEER AND
OWNER, THAT THE INDEMNITY PROVIDED FOR IN THIS PARAGRAPH IS
INDEMNITY BY ENGINEER TO INDEMNIFY AND PROTECT OWNER FROM
THE CONSEQUENCES OF ENGINEER'S PARTIES' OWN WILLFUL
MISCONDUCT, JOINT OR SOLE NEGLIGENCE AS WELL AS ENGINEER'S
PARTIES' INTENTIONAL TORTS, INTELLECTUAL PROPERTY
INFRINGEMENTS, AND FAILURES TO MAKE PAYMENTS ARISING OUT OF
OR IN CONNECTION WITH THIS AGREEMENT. SUCH INDEMNITY SHALL
NOT APPLY, HOWEVER, TO LIABILITY ARISING FROM THE PERSONAL
INJURY, DEATH, OR PROPERTY DAMAGE OF PERSONS THAT IS CAUSED
BY OR RESULTS FROM THE NEGLIGENCE OF ANY PERSON OTHER THAN
ENGINEER'S PARTIES. IN THE EVENT THAT ANY ACTION OR
PROCEEDING IS BROUGHT AGAINST THE OWNER FROM WHICH THE
OWNER IS INDEMNIFIED, ENGINEER FURTHER AGREES AND COVENANTS
TO DEFEND THE ACTION OR PROCEEDING BY LEGAL COUNSEL
ACCEPTABLE TO THE OWNER. THE INDEMNITY PROVIDED
HEREINABOVE SHALL SURVIVE THE TERMINATION AND/OR EXPIRATION
OF THIS AGREEMENT.
By this Agreement, the OWNER does not consent to litigation or suit, and the OWNER hereby expressly
revokes any consent to litigation that it may have granted by the terms of this Contract or any other
contract or agreement, any charter, or applicable state law. Nothing herein shall be construed so as to
limit or waive OWNER'S sovereign immunity. ENGINEER assumes full responsibility for its work
performed hereunder and hereby releases, relinquishes and discharges OWNER, its officers, agents, and
employees from all claims, demands, and causes of action of every kind and character for any injury to or
death of any person and/or any loss of or damage to any property that is caused by or alleged to be caused
by, arising out of, or in connection with ENGINEER's work to be performed hereunder. This release shall
apply with respect to ENGINEER's work regardless of whether said claims, demands, and causes of action
are covered in whole or in part by insurance.
The protections afforded to OWNER in this Exhibit K shall control and supersede any
apportionment of liability or release of liability contained elsewhere in the Contract Documents.
Furthermore, the provisions contained in this Exhibit "K" shall survive the termination and/or
expiration of this Agreement.
P-4- LI -11- AIM
it
LE
cm w
LLI <
X
L) -All
LJ
Z LLI
UJ U)
0
ILo' Nx
IL 0
U)
Owz
z
M..
In
r
It)
. l Sk .4
w
PR
IL W
W4) z
0 ik
A. -
L) 0
Li- Z 4;v
z
La
z
0
00
o0 . 4A
CO3
4„r,;> �
Lif
71
rRu
x
:3 U)
in
cn
w
X-C z
U) 7!1
Old
I V
S2
f
(n
IN
z
ke; L
A
wlw Go
N.
ul w
(Lzo
de
MWLI
Ld
U
JO
W